Site work and new construction of a fire / police facility in Woodstock, Georgia. Working plans call for the construction of a fire / police facility; and for site work for a fire / police facility.

The CMAR will work with the Architect and the City and review construction documents in process through completion to ensure the feasibility and constructability of the Architects design, and that the cost of construction of the Project is within the estimated Construction Budget through value engineering, the selection of construction systems and materials, cost estimating, scheduling, and other means. The CMAR will also review the project schedule and identify critical path and long lead items. Upon the completion of or during such preconstruction services, and prior to the completion of the 100% set of construction documents, the CMAR will submit a proposal of a Guaranteed Maximum Price for the construction of the Project, which is within the City's Construction Budget. Questions about any aspect of the RFQ, or the project, shall be submitted in writing via Vendor Registry. Refer to Schedule of Events for deadline for submission of questions relating to the RFQ City of Woodstock completes evaluation and issues notification and other information to finalist firm 05/31/24 RFQ selection criteria will consist of the following: Selection Criteria for Fire Station Construction Manager at Risk Services Criteria 1 - Historical Experience Constructing Similar Projects 30 points Criteria 2 - Demonstrated Ability to Deliver High Quality Construction and Workmanship 25 points Criteria 3 - Relevant Experience and References for Principles and Personnel Assigned to Project 20 points Criteria 4 - Demonstrated Ability to Deliver Project within Schedule and Budget 15 points Criteria 5 - Demonstrated Ability to Provide a Professional Working Relationship with City Staff, Consultants, and Engineers Through Completion of Project 10 points Total points possible 100 points . The City reserves the right to accept or reject any and all bids or any or parts of a bid wherein its judgment, it will be in the best interest of the City; waive any technicalities/informalities in the RFQ document and bid process; and to qualify and award any or all of this contract in any manner in which the City, acting in the sole and exclusive exercise of its discretion, deems to be in the City's best interest. If no acceptable qualifications are received, the City also reserves the right to re-solicit qualifications, at its sole discretion. For further information regarding this RFQ, please call 770-592-6000 ext. 1205. For all questions about this RFQ contact: Martyn Detz Financial Analyst: Purchasing 770-592-6000 Ext 1205