Site work for a playground / park / athletic field in Birmingham, Alabama. Completed plans call for site work for a playground / park / athletic field.

** As of May 1,2025, project has to be rebid. No definite date for the rebid.** Bids are invited upon the following work, but not limited to, as follows: Installation of Little Tykes Playground equipment supplied by Jefferson County Housing Authority. Installation to include some demolition of existing equipment, replacement of existing equipment and installation of new equipment. The installations will be at four locations. Bids must be accompanied by a certified check or bank draft payable to the order of Jefferson County, Alabama negotiable U.S. Government Bonds (at par value) or a satisfactory Bid Bond executed by the bidder and an accept- able surety, in the amount equal to five percent (5%) of the total of the bid amount but not to exceed $10,000.00, for the construction of Jefferson County Housing Authority Park Improvement Project (CD22-03F-CW- JCH) The bid security is to become the property of the owner in the event that: (1) the bidder fails to meet any of the qualifications required in the bid spec- ifications stated herein; (2) the bidder misrepresents or falsifies any informa- tion required to be provided by the owner; (3) for any reason that the bid- der fails to qualify, causing his bid to be withdrawn or rejected and such withdrawal or rejection results in delay or substantial additional expense to the owner; (4) the contract and bond are not executed within the time set forth, as liquidated damages for the delay and additional expense of the owner caused thereby. The Owner reserves the right to reject any or all proposals and to waive technical errors if, in the Owners judgment, the best interests of the Owner will thereby be promoted. Bidders are advised that submitted. The Jefferson County Commission reserves the right to reject any or all bids or to waive any informalities in the bidding. This project will be funded in its entirety (100%) with Federal Community Development Block Grant Funds. No Bid may be withdrawn for a period of sixty (60) days from the date of the opening of bids to allow the Jefferson County Commission to review the bids and investigate the qualifications of bidders, prior to awarding the contract. The Owner reserves the right to reject any or all proposals and to waive technical errors if, in the Owner's judgment, the best interests of the Owner will thereby be promoted. Bidders are advised that submitted bids bind the bidders to the Bid Conditions Setting Forth Affirmative Action Requirements for all Non Exempt Federal and Federally assisted Construction Contracts to be awarded in Jefferson, Shelby and Walker Counties, Alabama, also known as the Birmingham Hometown Plan. The Jefferson County Commission reserves the right to reject any or all bids or to waive any informalities in the bidding. This project will be funded in its entirety (100%) with Federal Community Development Block Grant Funds.