Site work for a mixed-use development in Alabaster, Alabama. Completed plans call for site work for a stadium; and playground / park / athletic field.

The Project consists of the procurement and installation of the Landscaping at Larry Simmons Stadium and the Jim "Peanut" Davenport Field, including but not limited to the removal of any unsuitable soils, placing topsoil, fine grading of the landscape areas, installation of plants, mulch, warranty of plants, and hand watering of plants for up to 120 days after Substantial Completion. A cashier's check or Bid Bond payable to the City of Alabaster in an amount of not less than five (5) percent of the amount of the proposal, but in no event more than $10,000 must accompany the bid. Performance and Statutory Labor and Material Payment Bonds in the amount of 100% of the Contract Price will be required at the signing of the Contract. All bidders must submit three (3) copies of their bids on proposal forms furnished by the Architect or copies thereof. All bidders bidding in amounts exceeding that established by the State Licensing Board for General Contractors must be licensed under the provisions of Title 34, Chapter 8, Code of Alabama 1975 and must show evidence of license before bidding or the bid will not be received or considered by the Architect; the bidder shall show such evidence by clearly displaying his or her current license number on the outside of the sealed envelope in which the proposal is delivered. The successful bidder must provide evidence of enrollment in the e-verify program per The Alabama Immigration Law (also referred to as "Act 2011-535" and codified in state law as Title 31, Chapter 13 of the Code of Alabama 1975) and amended by Act No. 2012-491 (2012) before awarding of contract. The Owner reserves the right to reject any or all the proposals and waive technical errors if, in the Owner's judgement, the best interest of the Owner will thereby be promoted. Drawings and Project Manual will be open to public inspection, at the offices of the City of Alabaster and CMH Architects, Inc. Bidders must call the Owner's and/or the Architect's office at least 24 hours in advance to arrange a time to review the documents at those locations. These documents cannot be removed from the Owner's or Architect's office, nor will any copies of these documents be provided to the bidders. The project is being bid Excluding Taxes and requires the Contractor to comply with the requirements of Act 2013-205 which was signed into law May 19, 2013. The Contractor and Owner will be required to apply for Certificates of Exemption with the Alabama Department of Revenue which will handle the administration of the certificates. The contractor shall account for the tax savings on the Accounting of Sales Tax form included in the specifications behind the proposal form. Failure for the Contractor to complete this form and include it with their proposal shall render the bid non-responsive. The City of Alabaster will waive the Alabaster building permit fees. Other fees and licenses shall be the responsibility of the Contractor. Performance Time: The project is a single-phase project and is to be complete within 90 calendar days from the Notice to Proceed. Liquidated damages apply to this project per the Supplementary Conditions. Contact Person: Earnest Clark 1953 Municipal Way Alabaster AL 35007 Email: eclark@cityofalabaster.com 205-378-1571