Renovation of a military facility in Custer, South Dakota. Completed plans call for the renovation of a military facility.

vSCOPE OF CONTRACT This Project is located at various recreation sites on Black Hills National Forest. The scope of work for this project includes the following: 1) Removal and replacement of roofing systems on various informational kiosks, restroom buildings, and pumphouses located throughout the Black Hills National Forest. The Contractor shall be responsible for removal and disposal of materials removed on each building, assessing deck and fascia board, and providing and installing new roofingsystems and as described in the Project Specifications. 2) Remove and replace siding and/or fascia on various informational kiosks, restroom buildings, and pumphouses located throughout the Black Hills National Forest. Contractor shall be responsible for removal and disposal of all siding on each building, assessing condition of building wrap and sheathing, and providing and installing new building wrap, sheathing, and siding as described in the Project Specifications. Contractor shall be responsible for all materials, equipment, labor, and incidentals necessary to complete the work and includes painting/staining all exposed exterior wood siding, trim, columns, and beams for each building awarded. The Contractor shall be responsible for field verifying all dimensions and quantities of materials required on this project. This project consists of Base Items and Optional Items. Base Items will be awarded at the agreed upon price. Optional Items may or may not be awarded depending on price and availability of funding. If Option Items are awarded, work shall begin on Optional Item(s) as designated by the Government Contracting Officer. The Government shall have 30 days after initial award to award Optional Items at the original submitted price. ALL construction activities shall be performed in accordance with all applicable OSHA standards or regulations. Some of the safety hazards that may be encountered while working on this site will be use of ladders, lifts, hoists, various hand tools, working on sloped surfaces, use of fall protection equipment, and use of applicable PPE. The Contractor will be required to cooperate with Government during construction operations to minimize conflicts and facilitate Government usage. Work shall be performed so as not to interfere with Government's day-to-day operations. Work shall be scheduled to minimize impacts to Government. All constructions operations shall be confined to immediate area of work. Contractor shall sweep and clean work areas and accessways daily to remove nails, screws, staples, and other construction debris and minimize hazards to government employees, vehicles, and the public. Contractor shall not disturb portions of site that are not included in the described Work. Contractor shall provide schedules in electronic format and include a written summary narrative to explain basis of approach to work. Schedule contract work and monitor progress using a Critical Path Method (CPM) or similar type scheduling system. Prepare construction Schedule to complete the Work within the contract time requirement. The anticipated start date for this project is 09/16/2024. The expected completion date is 05/16/2025 In accordance with FAR 36.204(b), the estimated price for this project is between $25,000 and $100,000. Questions shall be emailed to tony.taylor@usda.gov. Questions are due by 12:00 noon (MT) on July 2, 2024. *The value for this project is based on a financial range. The value is listed as the highest possible cost from the range provided by a stakeholder or official project document.