Site work and new construction of a mixed-use development in Boaz, Alabama. Completed plans call for site work for a playground / park / athletic field; for the construction of a playground / park / athletic field; warehouse / distribution facility; and warehouse / distribution facility.

The City of Boaz (Owner) invites qualified bidders to submit proposals for the renovation of an existing Softball Sportsplex Tower and construction of a new Restroom Building located at 225 Collier Street, and construction of a new Chemical Storage Building at 400 Elizabeth Steet for the Boaz Parks and Recreation Department, Boaz, Alabama. All material, equipment, vehicles, services, and labor, whether specifically set forth in bid documents or not, which are necessary for the completion of all work, protection of adjacent property and buildings, removal of debris to legal landfill and remediation of the building and site, shall be included in the bid, including providing temporary electrical service for construction activities and potable water service and portable toilet facilities for the contractor's employees. A bid bond executed by a qualified surety company or a cashier's check, made payable to the City of Boaz, in the amount of five percent (5%) of the bid, but in no event more than $10,000, must accompany the bidder's proposal. Performance and Payment Bonds and evidence of insurance required in the bid documents will be required at the signing of the Contract. Within three (3) days after a contract is executed, the successful contractor shall be required to provide a Performance and Payment Bond, executed by a qualified surety company, in the amount of 100 % of the contract. The construction start date shall be no later than August 30, 2024. The work on the Softball Tower and Restroom Building must be fully completed, operational and made available to the Owner no later than February 28, 2025, and the Chemical Storage Building will be completed on April 30, 2025. The successful contractor will be allowed to work 7 days a week, nights, and weekends, if required, to complete the work on the above schedule. This project includes Liquidated Damages in the amount of $300.00 per calendar day for failure to complete work by schedule listed above. Failure to adequately staff the work, failure to pursue the work in a timely manner or failure to meet milestones of contractor's construction schedule can be grounds for terminating this contract. The Owner reserves the right to hold the bids for ten (10) days after the bid opening date to evaluate the bids and determine the lowest qualified bidder before making a verbal award. The Owner also reserves the right to reject any or all bids, or portion thereof, and to waive any defect or technicality if, in the Owner's judgment, the best interest of the Owner will thereby be served. The Owner assumes no responsibility to compensate or indemnify the bidders for any expense incurred in the preparation of their bid. Bids must be valid for thirty (30) days after the bid opening.