Renovation of an educational facility in Jamestown, Pennsylvania. Completed plans call for the renovation of a educational facility.

It is the intent of the Owner to enter into a single contract for the work. Bids shall include a Bid Security Bond or Certified Check, payable to Jamestown Area School District, in an amount of five percent (5%) of the bid, in accordance with Instructions to Bidders, as included in the Contract Documents. Such Bid Bond or Check shall be submitted with the understanding that it shall guarantee that the Bidder's Bid will not be withdrawn for a period of at least sixty (60) days after the scheduled closing time for receipt of bids; that if the Bid is accepted, the Bidder will execute the Form of Agreement, as provided by the Owner, with all blanks appropriately filled and will submit the required 100% Performance and Labor and Material Bonds (submitted on A.I.A. Document A312) and 100% Maintenance Bond as specified in Section 007216, Article 11; and that in the event of withdrawal of said Bid within said period, or the failure to enter into said Agreement and submit said Bonds within ten days after the Bidder has received notice of the acceptance of the Bid, the Bidder shall be liable to the above mentioned Owner for the full amount of such Bond or Check as representing the damage to the Owner on account of the default of the Bidder in any particular hereof. The Bid Bond or Check of all Bidders whose Bids are not accepted will be returned within ten calendar days after the scheduled bid opening date The Bidder shall submit his Bid with the understanding that (1) the Work shall be completed in accordance with Section 011000 "Scheduling Requirements of the Work", and the Final Project Completion Date(s) shall be as stated therein, (2) the time for the completion of the Work shall be considered of the essence of this Contract, and (3) for the costs of extra inspection, salaries of contingent forces and other expenses entailed by the Owner by delay in completing the contract, said Owner shall be entitled to liquidated damages in the following amounts: Final Project Completion Date $500.00 Final Project Closeout Completion Date $400.00 for each and every calendar day's delay from the Final Completion Date(s) specified, not solely caused by the Owner, provided however, that the Contractor shall be entitled to one day in addition to the time stipulated for each work day's delay that may be solely caused by the Owner or conditions beyond the control of the Contractor. Weather conditions will not be considered as reason for extension of time for completion of work. It is further understood, however, that any extensions of time, regardless of cause, must be requested by letter originated by the Contractor, and the Owner must grant such extensions by letter prior to same becoming effective. The Contract will be awarded as soon as possible to the lowest responsible Bidder, provided the bid is reasonable and it is in the interest of the Owner to accept it. The Owner shall have the right to accept Alternates in any order or combination and to determine the low Bidder on the basis of the sum of the Base Bid and Alternates accepted on the date of Contract Award. The Owner reserves the right to waive any informality in bids when such waiver is in the interest of the Owner. The Owner reserves the right to reject any and all bids when such rejection is in the interest of the Owner, and to reject the bid of any Bidder, who in the Owner's judgment, is not in position to perform the Contract. Each Bidder agrees to waive any claim it has or may have against the Owner, the Architect/Engineer, and their respective employees, arising out of or in connection with the administration, evaluation, or recommendation of any bid Final Project Completion Date - August 1, 2025 Final Project Closeout Completion Date - September 1, 2025