Renovation of a municipal facility in Madison, Wisconsin. Completed plans call for the renovation of a municipal facility.

Construction Services to Replace All Existing Reheat Control Valves, Fin Tubes, and Radiant Panels on the 4th Through 8th Floors of the Dane County Courthouse. Emerging Small Business (ESB) Goal. The goal of this project is ten percent (10%) ESB participation. ESBs utilizations are shown as a percentage of the total Bid. Project Description: Perform the Work as specified and detailed in Construction Documents package. Base bid is for contractor to furnish and replace all existing control valves serving reheat coils, fin tubes, and radiant panels on the 4th through 8th floors of the Dane County Courthouse by the expected completion date of December 20, 2024. Contractor to match existing CV per valve schedule, verify control signals, and match actuators to function with existing VAV controllers. Contractor will also be responsible for wiring these replacement valves into the courthouse's existing HVAC system. After hours work could be accommodated to hit completion date if required. Include after-hours rates in bid. Please note in the bid form if base bid is not anticipated to be achievable by expected completion date. Question Deadline 08/23/2024 No verbal explanation or instructions will be given in regard to meaning of Drawings or Specifications before Bid Due Date. Bidders shall bring inadequacies, omissions or conflicts to Owner & Architect, Engineer or Consultant's attention at least ten (10) calendar days before Bid Due Date. Prompt clarification will be available to all bidders by Addendum.