Site work and paving for a civil project in Port St Joe, Florida. Completed plans call for site work for a road / highway; for paving for a road / highway; and water / sewer project.

Qualified person, company or corporation interested in constructing This project consists of roadway repairs for various roads located in Port St. Joe Florida. This project also involves stripping and other safety improvements. All bidders shall be FDOT Qualified per Section 2-1 of the FDOT Standard Specifications for Road and Bridge Construction, latest edition in the following work classes: Grading, Drainage, Flexible Paving, and Hot Plant Mix Bituminous Course. The completion date for this project will be 90 days for Substantial Completion and 120 days for Final Completion from the date of the Notice to Proceed presented to the successful bidder. Liquidated damages for failure to complete the project on the specified date will be set at $500.00 per day. The City of Port St. Joe reserves the right to waive informalities in any bid, to accept and/or reject any or all bids, and to accept the bid that in their judgment will be in their best interest. All bids shall remain firm for a period of sixty days after the opening. Questions regarding the project must be submitted in writing to Josh Stephens at jstephens@dewberry.com prior to October 11, 2024. All bidders shall comply with all applicable State and local laws concerning licensing registration and regulation of contractors doing business to the State of Florida. The City of Port St. Joe is an Equal Opportunity, Affirmative Action Employer, and a Drug Free Workplace. Estimated cost is $1,937,520.69.