Renovation of a residential development in Sacramento, California. Completed plans call for the renovation of a residential development.

Project Location: 3929 48th Ave, Sacramento, CA 95823 and 5259/5251 Young Street, Sacramento, CA 95824 The Housing Authority of the County of Sacramento is soliciting sealed bids for Invitation for Bid 2430-KPas - Pointe Lagoon Camera Project for the purchase and installation of "state-of-the-art" security camera surveillance systems (Digital Watchdog) throughout the campus at two sites within the County of Sacramento. The installation will include all equipment and labor necessary to provide an additional measure of safety for the residents, and Agency staff. located at 3929 48th Ave, Sacramento, CA 95823, 5259 Young Street, Sacramento, CA 95824 and 5251 Young Street, Sacramento, CA 95824. Possible subcontracting trades are None. The estimated bonding range is $200,000-$225,000. Licensed California C-7 Low Voltage Systems and/or C-10 General Electrical contracting license are encouraged to attend the Pre-Bid Conference(s) to be held at the location(s), date(s), and time(s) indicated in the Timeline. Question Deadline 11/04/2024 at 10:00 AM PT Please direct all general and contractual questions to Keith Peloquin, Buyer - Procurement Services, at kpeloquin@shra.org. For any questions regarding the Technical Plans and Specifications, all questions must be submitted via electronically. For information on other construction projects, visit online. Addendum Issued (Lock Wages): October 29, 2024 The Contractor shall complete all work required under this contract within One Hundred Twenty (120) enter duration calendar days of the effective date of the contract, or within the time schedule established in the notice to proceed issued by the Contracting Officer. Refer to Section 01311 Progress Schedule in the Technical Specifications. Bidder understands that the Agency retains the right, in its sole and exclusive discretion to (1) reject all bids for the subject project(s) and (2) waive any informalities in its consideration and review of the submitted bids. If the Contractor fails to complete the work within the time specified in the contract, or any extension, as specified in the clause entitled Default of this contract, the Contractor shall pay to the PHA as liquidated damages, the sum of ___$100___ per unit for each calendar day of delay. If different completion dates are specified in the contract for separate parts or stages of the work, the amount of liquidated damages shall be assessed on those parts or stages which are delayed. To the extent that the Contractor's delay or nonperformance is excused under another clause in this contract, liquidated damages shall not be due the PHA. The contractor remains liable for damages caused other than by delay. This contract is subject to The Davis-Bacon Act,, Section 3 Requirements of the HUD Act of 1968,, Federal labor standards,. For bids in excess of $25,000, bidders will be required to furnish and pay for a satisfactory Bid Bond in the amount of not less than 5% of the total bid price. The successful bidder will be required to furnish and pay for a satisfactory Performance Bond and Payment Bond in the amount of not less than 100% of the contract price. Pursuant to the California Public Contract Code Section 22300 the Contractor may request that the Agency substitute a security in the amount of the performance retention. This is a Public Works project. Per California State Labor Code Section 1771.1 (a), a contractor or subcontractor shall not be qualified to bid on, be listed in a bid proposal, subject to the requirements of Section 4104 of the Public Contract Code, or engage in the performance of any contract for public work, as defined in this chapter, unless currently registered and qualified to perform public work pursuant to Section 1725.5. Notwithstanding any other requirements (including federal labor requirements), this contract is subject to compliance monitoring and enforcement by the Department of Industrial Relations (DIR). The Housing Authority of the County of Sacramento reserves the right to reject any or all bids and waive any informalities in the bidding. The Agency/Authority is an Equal Opportunity Employment employer. *The value for this project is based on a financial range. The value is listed as the highest possible cost from the range provided by a stakeholder or official project document.