This is a service / maintenance or supply contract in Naugatuck, Connecticut. Contact the soliciting agency for additional information.

The project consists of excavation, transportation, and disposal of approximately 150 cubic yards of controlled / low impacted soil (low level PCB Remediation Waste) and site restoration with clean fill; excavation, segregation, processing, and placement of approximately 7,500 CY of building demolition debris and fill material; general grading, excavation, and recycling of existing pavement and processed aggregate base. Per CONN. GEN. STAT. 4b-91, all bidders for this State Funded project must be prequalified through the Department of Administrative Services (DAS) Construction Contractor Prequalification Program for the Contractor Classification: SITEWORK. State law requires a minimum of twenty-five (25%) percent of the state-funded portion of the contract for award to subcontractors holding current certification from the Connecticut Department of Administrative Services ("DAS") under the provisions of CONN. GEN. STAT. 4a-60g. (25% of the work with DAS certified Small and Minority owned businesses and 25% of that work with DAS certified Minority, Women and/or Disabled owned businesses.) The contractor must demonstrate good faith effort to meet the 25% set-aside goals. The minimum rates to be paid labor of the various classifications shall be in accordance with the current schedule of wages established by the State Labor Commissioner as provided in the General Statutes of Connecticut, as revised. The Contract Wage Certification Form is to be submitted to the Labor Commissioner before the award of the contract. Bids must be accompanied by a certified check or Bid Bond in writing on forms provided by the Borough of Naugatuck in the amount of at least 5% of the amount of the Bid and payable to the order of the Borough of Naugatuck. The successful Bidder will be required to furnish and pay for a Performance Bond and a Payment Bond in the amount of one hundred percent (100%) of the Contract price. The right is reserved by the Borough of Naugatuck to reject any or all Bids, to waive any informalities or defects in Bids, and to make such time extensions as may be necessary in order to review and compare Bids, to obtain such supplemental information as may be necessary to review Bids and to accept Bid(s) that, in the judgment of the Borough of Naugatuck, will be in the Borough's best interest. No Bidder may withdraw his bid within (90) days after the actual date of the opening thereof. An affirmative Action/Equal Opportunity Employer. Minority/Women's Business Enterprises are encouraged to apply. This contract is subject to State set-aside and contract compliance requirements.