Renovation of a mixed-use development in North Chicago, Illinois. Completed plans call for the renovation of a 12,590-square-foot medical facility.

Project Name: Renovate B134-2C CLC Location: B134 C-wing 2nd Floor CLC Captain James A. Lovell FHCC 3001 Green Bay Rd, North Chicago, IL 60064 Part 1: Project Scope of Work Overview: Contractor shall provide all tools, materials, labor, quality assurance, and supervision for renovations resulting in a complete, compliant, and fully-functional CLC, including erection of temporary enclosures preventing the release of dust outside of the work area, selective demolition, metal studs, gypsum wall board, paint, ceilings, flooring, electrical power and light, modifications to the fire protection system, telecom cabling, fire alarm, and other work to affect a complete turn-key space supporting described clinical function(s) and equipment. Finished square footage is approximately 12,590. The current HVAC system and all its components installed on the roof will be tied into the new space on the 2nd floor. Part 2: Period of Performance: The following model presents the summary logic of the milestone sequence working backward from the delivery date of the longest lead time in the critical path to determine a mobilization date, and then forward from the delivery date of the longest lead time to completion of all work. Notes: Durations shown are in calendar days. Actual Award and NTP dates will be revised to match their occurrence. Time consumed for resubmission and review must be made up by the GC to ensure that all submittals of this contract are approved within 60 days of NTP. See Section 01 32 16.15 Project Schedules with Long Lead Items (D/B/B Projects at FHCC). Part 3: Detailed Project Requirements: Project Objectives: This project is required to renovate the described space as expediently and compliantly as practical. Meet or exceed all Code, technical, and programmatic requirements adopted, established, revised, and or published by VA or the many organizations listed in the several specifications. Expedite the delivery of a highly functional, complete, compliant, and safe workspace for the user service. List of AE Documents to be included in this Contract: See: 00 01 10 Table of Contents and the entire Project Manual See: 00 01 15 List of Drawing Sheets and the entire volume of drawings Pre-Bid Conference: VA shall schedule two pre-bid conferences required to be attended by prospective bidders to observe current conditions within the work area(s). The AE shall not attend the pre-bid events. No questions will be allowed during the events. All questions by all prospective contractors shall follow the RFI process described in the Solicitation. Prospective bidders shall not attempt to contact the AE or VA facilities engineering staff during the solicitation and bidding period. The AE and VA facilities engineering staff are instructed to ignore all such inquiries and report them to the VA Contracting Officer. All inquiries regarding this project shall be presented as complete and coherent Requests for Information (RFI) specifically citing design or specification sections, pages, paragraphs, notes, details, etc. to enable responses to RFI s. Follow the instructions provided by the Contracting Officer within the Solicitation regarding submission of RFI s. Two (2) organized site visit is scheduled as outlined below: 1st Site Visit: Tuesday, January 21, 2025 at 9:00 am CST; 2nd Site Visit: Tuesday, January 28, 2025 at 9:00 am CST Project is prevailing wage.