Site work for a bridge / tunnel in Israel Township, Ohio. Completed plans call for site work for a bridge / tunnel.

If the bid is sent by mail or delivery service, ensure that the outside of the envelope is marked clearly that a sealed bid is enclosed. Also, include in the sealed envelope one original and one copy of the bid. The Preble County Commissioners reserve the right to accept or reject any or all bids; to waive any irregularities in bidding; and to enter into a contract(s) with the bidder or bidders who in their consideration offered the lowest and best bid. Bid must contain the full name of the party or parties submitting the bid and all persons interested in therein. Each bidder must submit evidence of experience on projects of similar size and complexity, and a complete listing of all subcontractors to be used. Completion Date of This Project is August 29, 2025. Project Must Use Prevailing State Wage Rates That Are Included With Bid Packet. Each bid must be accompanied by cashier's check or certified check issued by a responsible bank or trust company and payable to the order of the Preble County Commissioners or by a bid bond acknowledged by the bidder, as principal, and by a surety company qualified to do business in the State of Ohio and satisfactory to the owner, as surety. The cashier's check or certified check shall be in the sum of ten (10%) percent of the bid. The bid bond shall be in the sum of 100% of the bid, which includes the total of the base bid and any alternates, as per ORC requirements. Once the bid is awarded, the successful bidder agrees to furnish a performance bond for the total amount of the TR-317 Pleasant Valley Road Bridge Beam Removal Project. Agreement Included in Bid Packet is for Informational Purposes Only. If Bid is Accepted, Contractor Will Be Expected to Sign Enclosed Agreement. The Preble County Commissioners' Office Hours are from 8:00 a.m. to 4:30 p.m., The Preble County Engineers' Office Hours are from 7:30 a.m. to 4:00 p.m., Monday through Friday. The Engineer's Estimate for the enclosed TR-317 Pleasant Valley Road Bridge Beam Removal Project is $82,500. The County reserves the right to reject any or all bids and to waive any irregularities in the bid, or to accept that bid, which in the judgment of proper officials is to the best interest of the County. The County reserves the right to accept a part or parts of a bid unless otherwise restricted in the bid.