Site work and new construction of a warehouse / distribution facility in Boaz, Alabama. Completed plans call for the construction of a warehouse / distribution facility; and for site work for a warehouse / distribution facility.

Project Name: New Chemical Storage Building, Boaz, AL. The City of Boaz, Alabama (Owner) invites qualified bidders to submit proposals for constructing a new 22'-6" x 14'-2" x 10 ft. high, wood framed, two room, chemical storage building located at 400 Elizabeth St. near the Boaz Parks and Recreation Building. The exterior finish shall be brick and metal siding to match the adjacent building with an architectural standing seam metal roof over wood decking and rafters. All material, equipment, vehicles, services, and labor, whether specifically set forth in bid documents or not, which are necessary for the completion of all work, protection of adjacent property and buildings, removal of debris to legal landfill and remediation of the building and site, shall be included in the bid, including providing temporary electrical service for construction activities and potable water service and portable toilet facilities for the contractor's employees. Bidder(s) must be Alabama licensed general contractors per Alabama Licensing Law: Chapter 8 of title 34, Code of Alabama, and must hold a current license. If subcontractor(s) are used, they must also comply with requirements of all Alabama Licensing Laws. Sealed envelopes containing two copies of bids on Proposal Form shall bear the following endorsement: "Boaz Parks and Recreation Chemical Storage Building, Boaz, AL. The envelope must also contain the name of the bidding organization and his/her current Alabama contractor's license number. Bids must be on the Proposal Form included with the bid documents and must contain the following to be considered: 1. Signature(s) of company representative(s) qualified to bind contract. 2. The contractor's Alabama General Contractor license number. 3. A bid bond executed by a qualified surety company or a cashier's check, made payable to the City of Boaz, in the amount of five percent (5%) of the bid, but in no event more than $10,000, must accompany the bidder's proposal. Performance and Payment Bonds and evidence of insurance required in the bid documents will be required at the signing of the Contract. Unsolicited alternates will not be considered in the bid evaluation for low bidder on this project, but they may be included as separate attachments to the Proposal Form. Bids shall be opened and read aloud publicly by the Architect. The Owner reserves the right to hold the bids for ten (10) days after the bid opening date to evaluate the bids and determine the lowest qualified bidder before making a verbal award. The Owner also reserves the right to reject any or all bids, or portion thereof, and to waive any defect or technicality if, in the Owner's judgment, the best interest of the Owner will thereby be served. The Owner assumes no responsibility to compensate or indemnify the bidders for any expense incurred in the preparation of their bid. Bids must be valid for thirty (30) days after the bid opening. Within three (3) days after a contract is executed, the successful contractor shall be required to provide a Performance and Payment Bond, executed by a qualified surety company, in the amount of 100 % of the contract. The construction start date shall be no later than January 27, 2024. The work on the Chemical Storage Building must be fully completed, operational and made available to the Owner no later than June 27, 2025. The successful contractor will be allowed to work 7 days a week, nights, and weekends, if required, to complete the work on the above schedule. This project includes Liquidated Damages in the amount of $300.00 per calendar day for failure to complete work by schedule listed above. Failure to adequately staff the work, failure to pursue the work in a timely manner or failure to meet milestones of contractor's construction schedule can be grounds for terminating this contract. The successful contractor is expected to order materials between the award and construction start date to have materials available before construction begins. The contractor will be allowed to store materials onsite prior to construction. If required, the successful contractor shall have the option of building, at the contractor's expense, a temporary exterior secured storage area onsite. All materials, subject to deterioration or damage if exposed to the elements, shall be stored in a weatherproof structure(s) or container(s). All exterior storage area(s), and/or container(s), shall be removed from the site by the contractor when construction is complete. All work shall be performed in strict conformance with applicable State, local, and Federal laws, and regulations, including the Occupational Safety and Health Regulations (OSHA).