Site work for an educational facility in Toledo, Ohio. Completed plans call for site work for a educational facility.

**As of March 20th, 2025, this project has not yet been awarded. A timeline for the award has not yet been established.** Scope of Services or Materials identified by the University within this RFP that forms the basis of the Respondent Proposal. Anticipated Award Date: 02/25/25 Question Deadline 01/28/2025 UToledo Response to Questions by: 02/04/25 Respondents with questions or requiring clarification or interpretation of any section within this RFP must address these questions via e-mail to kimberly.sutton@utoledo.edu prior to the submission date stated in Section 2: RFP Schedule of Events. No phone calls will be accepted. The respondent needs to reference each question to the RFP in consecutive order, from beginning to end, following the chronology of the RFP. Each question should begin by referencing the RFP page number and section number to which it relates. Liquidated Damages. If actual and direct damages are uncertain or difficult to determine, the University may recover liquidated damages. Unless otherwise specified, liquidated damages will be in the amount of 1% of the value of the order, Deliverable, or milestone that are the subject of the default, for every day that the default is not cured by Contractor. The University reserves the right to cancel this RFP, in whole or in part, at any time before the opening of the proposals. Should it become evident during the evaluation of the proposals that it is no longer in the best interest of the University to make an award under this solicitation, the University reserves the right to cancel this RFP. The University shall not be responsible for any costs incurred due to the cancellation of the RFP. The University may make such investigations as deemed necessary to determine the ability of the Respondent to provide the supplies and/or perform the services specified. The University reserves the right to reject any Proposal if the evidence submitted by, or investigation of, the Respondent fails to satisfy the University that the Respondent is properly qualified. This includes the University's ability to reject the Proposal based on negative references