Demolition and site work for a playground / park / athletic field in Callicoon, New York. Completed plans call for the demolition of a playground / park / athletic field; and for site work for a playground / park / athletic field.

Work will generally include but is not limited to: . Grinding and resurfacing portion of existing tennis courts approximately 4,150 square feet. . Excavating, extending subbase and surface of court approximately 2150 square feet. . Demolition of approximately 102 linear feet of fence. . Furnish and Installation of approximately 100 linear feet of fence with two double-wide gates. . Removal of an LP fuel tank and pad within the bounds of proposed court. . Completion Date: June 30, 2025 Each bid must be accompanied by security in an amount not less than five percent (5%) of the amount of the bid in the form and subject to the conditions provided in the Information for Bidders. No Bidder may withdraw his bid within forty-five (45) days after the actual date of opening thereof. This is an exempt capital improvement project, and Bidders shall not include in their bid sales and compensating use tases on the cost of materials which are to be incorporated into the work. The Owner reserves the right to waive any informalities or irregularities in the Bids received, or to reject any or all Bids without explanation, and to select the Bid, the acceptance of which, in its judgment, will best assure the efficient performance of the work. Bidders are advised that Labor and Material and Performance Bonds, each in the amount of 100% of the contract prices, as well as a Certificate of Insurance demonstrating required coverage, shall be provided by the successful bidder(s). In addition, the successful bidder(s) shall provide a one-year maintenance bond in the amount of 100% of the contract price at the completion of work. Bidders are responsible for the timely delivery of their bid proposal to the proper person and location as indicated in this "Invitation to Bid". Bidders are advised not to rely on the Postal Service or any other mail delivery service for the timely and proper delivery of their bid proposal. Bid proposals received after the date and time specified in this invitation shall be considered unresponsive and will be returned to the Bidder unopened. The Contractors must also be aware that they must comply with the State wage rates under New York State Department of Labor PRC# 2025002714(dol.ny.gov). In addition, the Contractor must comply with Labor Law 220, section 220-h, which requires that on all public work projects of at least $250,000.00, all laborers, workers and mechanics on the site be certified as having successfully completed the OSHA 10-hour construction safety and health course. Each prime contractor shall provide proof of registration with the New York State Department of Labor in their bid packet. Effective December 30, 2024, all contractors and subcontractors submitting bids or performing construction work on public work projects or private projects covered by Article 8 of the Labor Law are required to register with the NYS Department of Labor (NYSDOL) under Labor Law Section 220-i. Specifically, contractors must register with the Department of Labor's Bureau of Public Work and Prevailing Wage Enforcement prior to bidding on public work projects or commencing work on public work projects or covered private projects that are subject to the prevailing wage. The stated purpose is to ensure that such contractors and subcontractors do not have previous labor law violations and that they will abide by the State's labor laws and regulations, including the prevailing wage requirements. These registration requirements go into effect on December 30, 2024. Consequently, after that date, local governments cannot award a contract for public work to a contractor unless they are registered with the State. For a site visit, please contact Alex Gardener at 845-887-5155. Technical questions are to be directed to William Brown P.E., at Delaware Engineering, D.P.C.'s Oneonta office; 55 South Main Street, Oneonta NY 13820, Phone: (607) 432-8073 Fax: (607) 432-0432, Email: wbrown@delawareengineering.com