Site work, paving and new construction of a mixed-use development in Missouri City, Texas. Completed plans call for the construction of a 5,000-square-foot clubhouse / community center; for site work for a clubhouse / community center; sidewalk / parking lot; and for paving for a sidewalk / parking lot.

It is the intent of Fort Bend County to contract with one (1) vendor for all materials, supplies, equipment, tools, services, labor and supervision necessary to complete the construction of one 5000 SF Kitty Hollow Park Community Center located at 9555 HWY 6, Missouri City, Texas 77459, hereinafter referred to as the Project, as specified herein. All bidders must submit, WITH BID, a cashier's check or certified check for at least five percent (5%) of the total bid price, payable to the order of Fort Bend County, or a Bid Bond in the same amount issued by a surety, acceptable to Fort Bend County, authorized to do business in the State of Texas, as a guarantee that the Bidder will do the work described herein at the rates stated herein. Unsuccessful bidders Cashier's Check or Certified Check will be returned only after a written request to do so have been received in the Office of the Fort Bend County Purchasing Agent. Performance and Payment Bonds: In the event the total accepted bid price exceeds $25,000 the Contractor must provide a payment bond in the amount of 100% of the total contract sum, and in the event the total accepted bid price exceeds $100,000 the contractor must also provide a performance bond in the amount of 100% of the total contract sum. Bonds must be submitted to the Office of the County Purchasing Agent within ten (10) calendar days after receipt of notification of bid award. The County and the Contractor recognize the delays, expense, and difficulties involved in proving in a legal or arbitration proceeding the actual loss suffered by the County if the work is not complete on time. Accordingly, instead of requiring any such proof, the County and the Contractor agree that as liquidated damages for delay (but not as a penalty) the Contractor shall pay the County $250.00 for each day that expires after the time specified herein for completion until the Work is complete, unless contract time has been adjusted by extension of time approved by Commissioners Court. Question Deadline 09/16/2025 at 9:30 AM CT. All requests for such interpretations must be made in writing addressed to Tyler Kendziora, Senior Buyer, 301, Jackson, Suite 201, Richmond, Texas, 77469, E-mail: Tyler.Kendziora@fortbendcountytx.gov. Fort Bend County reserves the right to accept or reject any surety company proposed by the Contractor.