Site work and paving for a road / highway in Atlanta, Georgia. Completed plans call for site work for a road / highway; and for paving for a road / highway.

This solicitation is being conducted by the Georgia Department of Transportation under its authority to procure services ancillary to the construction and maintenance of a public road (as defined in O.C.G.A 32-1-3 (24) as provided for in O.C.G.A 32-2-61 (c) and (d) (1) (D). Only contractors deemed as Qualified Contractors to provide "Pavement Preservation and Maintenance Services" during the prequalification process having an MSA agreement beginning with (48400-410-0000034480) are eligible to participate in this Invitation to Bid (ITB) / Request for Quote (RFQ). Through this ITB/RFQ the Georgia Department of Transportation (hereinafter, "the State Entity, Department, Agency, or GDOT") is seeking bids for Pavement Preservation and Maintenance Services. All respondents to this ITB/RFQ are subject to same terms and conditions of the MMSA 48400-410-0000034480, all respondents to this ITB/RFQ are subject to same terms and conditions of the RFQC 48400-410-0000033480, subsequent awarded contract, and the Invitation to Bid (ITB) / Request for Quote (RFQ) Form, and are cautioned to completely review the entire ITB/RFQ and follow instructions carefully. The Department reserves the right to modify existing provisions or include additional provisions, which are not currently addressed herein and further reserves the right to reject any or all bids, and to waive technicalities and in-formalities at its discretion. Question Deadline 04/23/2025 at 2:00 PM ET Deadline for Written Questions from Contractors All questions concerning this ITB must be submitted in writing via email to the Issuing Officer identified in Table 1 - General Information. No questions other than written will be accepted. No response other than written will be binding upon the State. All suppliers must submit questions by the deadline identified in the Schedule of Events for submitting questions Bid Bonds or Proposal Guarantys are no longer required 1. The Department will require the awarded Contractor to begin and complete work within the timeframe above and meet all project milestones outlined in table 9.1 Project Milestones. 2. The Prework Meeting Document with a detailed project milestone schedule including actual completion dates will be signed by both parties at the Prework Meeting. 3. The Contractor is required to schedule, with the Department, the start of any work related to this ITB a minimum of 48 business hours in advance. 4. The Contractor must also confirm the schedule or inform the Department of any changes to the schedule each morning work is to be performed. 5. Completion of work includes Department inspections and any work required to correct deficiencies noted by the Department.