Site work and paving for a civil project in Jacob, Florida. Completed plans call for site work for a bridge / tunnel; road / highway; for paving for a road / highway; and water / sewer project.

The City of Jacob, FL, in NW Jackson County, will receive sealed bids for construction services for the following project: Jacob City-wide Drainage and Paving (federal/state CDBG-DR M0102 grant funded). Question Deadline 10/01/2025 All requests for bid documents or any questions, please contact Jon Sims at (850)354-5188 or at jsims@dewberry.com). All questions about the meaning or intent of the Bidding Documents are to be submitted to Engineer in writing. Questions received less than seven days prior to the date for opening of Bids may not be answered. This project consists of clearing existing ditches, replacing/installing drainage structures, including approximately 1025 LF of culverts plus associated end sections, as well as up to 1.5 miles of road paving. A 5% bid bond is required. Final completion date for this project will be 210 days from the date of the Notice to Proceed. Liquidated damages for failure to complete the project on the specified date will be set at $200.00 per day. Bidders shall comply with all applicable State and local laws concerning licensing registration and regulation of contractors doing business in the State of Florida. The bid must conform to Section 287.134 Florida Statutes, on discriminatory vendors. Pursuant to section 287.133(2)(a), F.S., a person or affiliate, as defined in section 287.133(1), F.S., who has been placed on the convicted vendor list following a conviction for a public entity crime may not submit a bid, proposal, or reply on a contract to provide any goods or services to a public entity; may not submit a bid, proposal, or reply on a contract with a public entity for the construction or repair of a public building or public work; may not submit bids, proposals, or replies on leases of real property to a public entity; may not be awarded or perform work as a contractor, supplier, subcontractor, or consultant under a contract with any public entity; and may not transact business with any public entity in excess of thirty-five thousand dollars ($35,000) for a period of 36 months following the date of being placed on the convicted vendor list. The Bidder warrants that neither it nor any of its affiliates is currently on the convicted vendor list. The Bidder shall disclose if it or any of its affiliates is placed on the convicted vendor list. Bidder and subcontractors must also be eligible to receive federally funded contracts. Multiple federal and state regulations apply to this project, such as Davis-Bacon Act wage requirements, conflict of interest, equal employment and subcontracting, HUD Section 3, etc. The contract will be awarded to the lowest responsive (complete bid package submitted on time), responsible (qualified, eligible, acceptable references, etc.) bidder, subject to budget constraints and state approval. All Bids shall remain firm for a period of sixty days after the opening. Bids received after the deadline will not be accepted. The City accepts no responsibility for any expense related to preparation or delivery of proposals, reserves the right to reject any or all proposals, to waive technical errors and informalities, and to accept the proposal which, in its judgment, best serves the public interest. The City is an equal opportunity/drug-free employer/procurer.