Site work for a playground / park / athletic field in Troy, Alabama. Completed plans call for site work for a playground / park / athletic field.

A. General: Project name is as indicated in the Advertisement For Bids and as shown on the Contract Documents prepared by Lathan Mckee Architects, 631 S. Hull Street Montgomery, Alabama 36104. B. Contract Documents: Indicate the work of the Contract and related requirements and conditions that have an impact on the project. Related requirements and conditions that are indicated on the Contract Documents include, but are not limited to the following: 1. Existing site conditions and restrictions on use of the site including ingress and egress to the site. 2. Grading operations at the site. 3. The Contractor shall be responsible to secure the site during the execution of the work and provide proof of insurance including but not limited to General Liability, W/C, Auto, Equipment, Etc. C. Summary by References: Work of the Contract can be summarized by references to the Contract, General Conditions, Supplementary Conditions, the Project Manual, Technical Specification Sections, Drawings, Addenda and modifications to the Contract Documents issued subsequent to the initial printing of this Project Manual and the Drawings, and including but not necessarily limited to, printed material referenced by any of the above. It is recognized that the Work of the Contract is also unavoidably affected or influenced by governing regulations, natural phenomenon including weather conditions, and other forces outside the contract documents. Question Deadline 10/21/2025 at 2:00 PM CT The Architect reserves the right not to answer any Request For Information received after prior to the bid date. To Lathan Mckee, Architects Chad Durbin, Project Manager durbinc@lathanmckee.com Troy City Recreation Baseball/softball Sportsplex Improvements Phase 1 All Bidders Shall Have Generalliability and Workman's Compensation Insurance and a Currentbusiness License With the Cityof Troy. The Project Shall Be Bidexcluding Taxes. Bids Must Besubmitted on Proposal Formsfurnished by the Architect Orcopies Thereof. The Owner Reserves the Right to Reject Any Orall Proposals and to Waive Technical Errors if, in the Ownersjudgment, the Best Interests Ofthe Owner Will Thereby Be Promoted. A Certified Check or Bid Bondpayable to the City of Troy Inan Amount Not Less Than Fivepercent (5%) of the Amount Ofthe Bid, but in No Event Morethan $10,000.00 Must Accompany the Bidder's Sealed Proposal. Performance and Statutory Labor and Material Paymentbonds Will Be Required at Thesigning of the Contract. All Bidders Bidding in Amountsexceeding That Established Bythe State Licensing Board Forgeneral Contractors Must Belicensed Under the Provisionsof Title 34, Chapter 8, Code Ofalabama, 1975, and Must Showevidence of License Before Bidding or Bid Will Not Be Receivedor Considered by the Architect. All Rfis and Rfas Regarding Thebid Documents Shall Be Sent Andaddressed Through Emails Foundon the Rfi and Rfa Forms in Theproject Manual. Note: Onlythe Rfi and Rfa Formsin the Project Manualwill Be Accepted. The Architect Will Not Accept Inquiriesvia Telephone or Fax. Completion Time: See Scopeof Work in Project Manual. Supervision: Contractor to Ensure Proper Supervision of Allwork.