Renovation of a municipal facility in Greenville, Alabama. Completed plans call for the renovation of a 4,621-square-foot, one-story above grade municipal facility.

A cashier's check or bid bond payable to Butler County Commission in an amount not less than five (5) percent of the amount of the bid, but in no event more than $10,000, must accompany the bidder's proposal. Performance and Payment Bonds and evidence of insurance required in the bid documents will be required at the signing of the Contract. Bid bonds are to be issued by an acceptable bonding company licensed to do business in the State, with a Power of Attorney, to confess judgment thereon, with the understanding that it shall guarantee that the bidder shall not withdraw his bid for the guarantee period of sixty (60) days after the scheduled closing time for the receipt of bids; that if his bid is accepted, he will enter into a formal contract with the Owner, and that in the event of a withdrawal of said bid within said period, or the failure to enter into said contract within the time specified, the bidder shall be liable to the Owner for the full amount of the bid guarantee as liquidated damages and not as a forfeit or as a penalty. The bid bond and certified checks on unsuccessful bidders will be returned upon awarding the contract or rejection of all bids, in no event, later than the number of days in the guarantee period from the opening of proposals. That of the successful bidder will be returned when formal contract and bonds are accepted and approved. Bids must be submitted on proposal forms furnished by the Architect or copies thereof. All bidders bidding in amounts exceeding that established by the State Licensing Board for General Contractors must be Licensed under the provisions of Title 34, Chapter 8, Code of Alabama, 1975, and must show evidence of license before bidding or bid will not be received or considered by by the Architect the bidder shall show such evidence by clearly displaying his or her current license number on the outside of the sealed envelope in which the proposal is delivered. The Owner reserves the right to reject any or all proposals and to waive technical errors if, in the Owner's judgment, the best interests of the Owner will thereby be promoted. The bidder's company employee attending the orebid conference shall have qualifications and experience with the construction to be performed within this project. Any questions concerning the prebid conference shall be directed to the Architect. Nonresident bidders must accompany any written bid documents with a written opinion of an attorney at law licensed to practice law in such nonresident bidder's state of domicile. as to the preferences, if any on none, granted by the law of that state to its own business entities whose principal places of business are in that state in the etting of any or all public contracts. ** doc info : Other sets for contractors, and sets for dealers, may be obtained with the same deposit, which will be refunded as above, less cost of printing, reproduction, handling, distribution. Electronic PDF copies of bid documents may be procured free of charge. Contractor's Responsibilities: The Work includes the following, as applicable: 1. Designate delivery dates of Owner-furnished products in Contractor's construction schedule, utilizing Ownerfurnished earliest available delivery dates. 2. Review Owner-reviewed Product Data, Shop Drawings, and Samples, noting discrepancies and other issues in providing for Owner-furnished products in the Work. 3. Receive, unload, handle, store, protect, and install Owner-furnished products. 4. Make building services connections for Owner-furnished products. 5. Protect Owner-furnished products from damage during storage, handling, and installation and prior to Substantial Completion. 6. Repair or replace Owner-furnished products damaged following receipt