Site work for a transportation facility in Saint Louis, Missouri. Completed plans call for site work for a runway / taxiway.

As of January 23, 2020, this project was Railworks Track Services, Inc., also low bidder $840,232. Notice to proceed was 1/14/2020. GENERAL DESCRIPTION The Contractor shall furnish engineering, design, labor, material, tools, equipment, and construction services necessary to provide total PROJECT SCOPE OF WORK AS HEREIN DESCRIBED. 1.2 OCCUPANCY The Contractor shall allow the Owner to take possession of and use any completed or partially completed portion ofthe facility during the progress ofthe Work as is possible without interfering with the progress ofthe Contractor. Possession and use ofthe facility shall not in any way evidence the completion ofthe Work or signify the Owner's acceptance ofthe Work or any part ofit. 1.3 NUMBER OF SPECIFIED ITEMS REQUIRED Wherever in these Specifications an article, device or piece of equipment is referred to in the singular number; such reference shall apply to as many such articles as are shown on the Drawings or required to complete the Work. 1.4 DRAWINGS FURNISHED BY THE OWNER The following Drawings and/or Exhibits (see list at the end of'Index of Specifications'), furnished by the Owner, shall be considered as part of and illustrating these Specifications. The Specifications are intended to supplement the drawings, the two being considered cooperative. The Drawings show the general character ofthe Work, but the Owner may furnish large-scale detail Drawings ofsuch portions, as in itsjudgment may be required, in the preparation of which slight modifications may be made in minor details of design, if necessary. The Contractor shall not execute any work requiring such large-size details until same has been approved and all work must be made in strict accordance with such detail Drawings. Dimensions on Drawings take precedence over measurements by scale, detail Drawings over small-scale Drawings, and full-size details over all other Drawings. The decision ofthe Owner shall be final as to the interpretations of Drawings and Specifications. The Contractor and its Sureties shall be liable for and shall pay to the Authority five thousand dollars ($5,000.00) as fixed, agreed and liquidated damages for each calendar day of delay from the completion date established in the Notice to Proceed, as is determined by the above Time for Completion, or as modified in accordance with Section 9, Changes in the Work in the Project Conditions until such work is satisfactorily completed and accepted (final completion). Substantial completion/beneficial occupancy shall not alleviate the Contractor’s liability for liquidated damages.