The successful bidder (Contractor) will provide general construction services for renovation of two rooms in ACB4 and 2 MRI installations Owner may evaluate the Proposals based on the anticipated completion of all or any portion of the Project. Owner reserves the right to divide the Project into multiple parts, to reject any and all Proposals and re-solicit for new Proposals, or to reject any and all Proposals and temporarily or permanently abandon the Project. Owner makes no representations, written or oral, that it will enter into any form of agreement with any Respondent to this solicitation for any project and no such representation is intended or should be construed by the issuance of this solicitation. Respondents are advised that the Texas Prevailing Wage Law will be administered in accordance with the policies and procedures set forth in the U. T. System document, entitled "Prevailing Wage Guidelines." A copy is attached to the Owner's Special Conditions, which are included as an Exhibit to the Owner's Standard Agreement. The penalty for violation of prevailing wage rates has been increased from $10.00 per underpaid worker per day or portion thereof to $60.00 per underpaid worker per day or portion thereof. Last Day to submit Request for Information 4:00 PM CST 05/13/2021
Response to RFI posted to Internet 05/17/2021
Owner determines Respondent offering "Best Value" 06/17/2021
Owner delivers agreement for execution to Selected Respondent 07/06/2021
Selected Respondent delivers executed Agreement to Owner 07/14/2021
Anticipated Date for Commencement of the Work 07/22/2021
Removal of existing MRI Units (Rigging out) 09/25/2021
Contractor achieves Substantial Completion 05/27/2022
Contractor achieves Final Completion 06/27/2022
.webp)
