Site work and new construction of an educational facility in Livingston, Alabama. Completed plans call for the construction of a educational facility; and for site work for a educational facility.

Untitled ADVERTISEMENT FOR BIDS Sealed proposals will be received by the UNIVERSITY OF WEST ALABAMA at MOON HALL PHYSICAL PLANT at University Drive, Livingston, Alabama; AT 2:00 PM LOCAL TIME ON May 6, 2022, at which time and place they will be publicly opened and read, for: UNIVERSITY OF WEST ALABAMA NEW TRACK & SOCCER FACILITY LVINGSTON, ALABAMA (PSCA Funds) The Work of the project includes, but is not limited to, installation of synthetic track surface and all field events, and natural grass soccer field, as specified and as indicated on the Drawings; coordination and supervision of the entire project; and all related work, as indicated in the Bid and Contract Documents. A cashier's check or bid bond payable to UNIVERSITY OF WEST ALABAMA in an amount not less than five (5) percent of the amount of the bid, but in no event more than $10,000, must accompany the bidder's proposal. Performance and statutory Labor and Material Payment Bonds, insurance in compliance with requirements, and verification of E-Verify enrollment (also with Proposals), will be required at the signing of the Contract. Drawings and Specifications may be examined at the Office of the Architect; and ConstructConnect. Bid documents (Plans, Specifications, and Addenda) will be sent to General Contractors only from the Architect electronically with no deposit. Contact John Bricken at john.bricken@gmcnetwork.com.Subcontractors should contact a General Contractor or plan room for documents. Bids must be submitted on proposal forms furnished by the Architect or copies thereof. Only General Contractors who are properly licensed in accordance with criteria established by the State Licensing Board for General Contractors under the Provision of Title 34, Chapter 8, Code of Alabama, 1975, as amended, will be considered for the Work of this project. A PRE-BID CONFERENCE will be held at Moon Hall, at 2:00 PM local time April 28, 2022 for the purpose of reviewing the project and answering Bidder's questions. Attendance at the Pre-Bid Conference IS MANDATORY for all General Contractor Bidders intending to submit a Proposal, and is highly recommended for Subcontractors. Any and all plan holders intending to submit a bid on the project referenced above must submit a written registration with the Architect prior to bid. There are no exceptions. Bidder Registrations may be emailed or faxed to: Goodwyn Mills and Cawood, attention: John Bricken Email: john.bricken@gmcnetwork.com or Fax: (334) 272-1566. Bids will not be accepted from unregistered bidders. It is the sole responsibility of the Bidder to confirm with the Office of the Architect receipt of registration. Per the Owner and the Alabama Department of Revenue (ADOR), Act 2013-205, the project will be bid EXCLUDING TAXES and will require the Contractor to complete ABC Form C-3A Accounting of Sales Tax Attachment to ABC Form C-3 Proposal Form (October 2013) which will be submitted with the Contractors Proposal at the time of the Bid. If awarded the bid, both tax exempt entity and contractor shall apply for certificates of exemption. ADOR shall issue certificates of exemption from sales and use tax for each tax-exempt project. Certificates shall only be issued to contractors licensed by the State Licensing Board for General Contractors or any subcontractor working under the same contract. Items eligible for exemption are building materials, construction materials and supplies and other tangibles that become part of the structure. ADOR will handle the administration of the certificates and the accounting of exempt purchases." Additional qualifications and requirements for General Contractor Bidders and separate Subcontractors are indicated in the Bid and Contract Documents. The Owner reserves the right to reject any or all proposals and to waive technical errors if, in their judgment, the best interests of the Owner will thereby be promoted. University of West Alabama Livingston, Alabama Dr. Ken Tucker, President GOODWYN, MILLS & CAWOOD, LLC. MEMBERS, AMERICAN INSTITUTE OF ARCHITECTS 2600 EastChase Lane, Suite 200 Montgomery, AL 36117 Phone: (334) 271-3200 Bham News: April 13, 2022