Renovation of a parking garage in Saint Augustine Beach, Florida. Completed plans call for the renovation of a parking garage.

Repairs consist of removal of existing shear transfer devices and installation of new devices. Repairs will occur on Levels 2, 3, and 4 along the expansion joint. contacting the City of St. Augustine by emailing or calling Barb Moore at bmoore@citystaug.com or 904-825-1010. Substantial completion of the project shall be no later than March 16, 2022. The Final Completion Date shall be no later than March 30, 2022. Every Request for Written Interpretation or Correction Must Be Received by January 5, 2022 All inquiries related to this solicitation should be directed to the Procurement Manager: Sharon Whitener, CPPO Phone: 904-209-4305 Fax: 904-825-1051 Email: swhitener@citystaug.com Any Delays Caused Due to Respondent's Failure to Accept the Terms of the Standard Contract Form After the Successful Bid Has Been Awarded May Result in Rejection of the Bid. Every request for a written interpretation or correction must be received at least nine (9) days prior to opening of bids in order to be considered (01/05/2022). Requests may be submitted by e-mail at swhitener@citystaug.com Each bid must be accompanied by a bid guaranty in the form of a bid bond or cashier's check, payable to the City, for five percent of the "Total Bid Cost" indicated on the bid. Cash will not be accepted. The bid bond must be written through a licensed Florida agency with a company licensed to do business in the State of Florida and meeting the requirements of the Agreement The City reserves the right to reject any bid if the evidence submitted by such Respondent and/or the City's independent investigation of such Respondent fails to satisfy the City that such Respondent is properly qualified to carry out the obligations of the Agreement and complete the Work in a manner acceptable to the City within the time period specified.