Site work and outdoor lighting for a mixed-use development in Houston, Texas. Completed plans call for site work for a road / highway; sidewalk / parking lot; and for outdoor lighting for a road / highway.

Provide all labor, materials, and equipment necessary and reasonably inferable to furnish and install bus shelters and seating, pedestrian lighting, associated electrical infrastructure and enhancement landscaping in accordance with the drawings and specifications prepared by PGAL and included in EXHIBIT E. Respondent agrees by submission of his proposal to start the work on the date specified in a written Notice to Proceed issued by the University of Houston and to complete the Project within 180 days (the Contract Time). Respondent agrees that by submission of his proposal to pay the following amounts for each consecutive date that the Project is not fully complete beyond the Contract Time as mutually agreed to liquidated damages and not as a penalty. Late Completion Day(s) Per Diem Amount 0-15 $ 250.00 16-30 $ 500.00 30+ $ 750.00 Questions Deadline February 15, 2022 @ 11 AM CST Notice to Proceed April 4, 2022 Substantial Completion October 28, 2022 Final Completion November 30, 2022 The University reserves the right to change this schedule at its sole discretion. Respondent shall submit by email any questions which may arise during the preparation of Proposal to the Point of Contact. Until the Contractor is identified and executes a contract for the Project on the Contract Form, all Respondents communications with respect to this RFP and/or the Project must be with the Point of Contact and not with any other employee, officer, Regent, agent, representative or contractor of Owner, except as expressly permitted Owners Reservation of Rights: Owner makes no representation of any kind that an award will be made as a result of this RFP or for the Project. Owner reserves the right to accept or reject any or all Proposals, waive any formalities or minor technical inconsistencies in Proposal, or reissue this RFP or delete any items/requirements from this RFP when deemed to be in Owners best interest. Selection of a Proposal, if any, will be made in strict compliance with the requirements of Texas Education Code