**As of April 11, 2022, the project has not been awarded yet. The Board approval for award is sheduled to appear on April 12th agenda. No start or completion dates have been set yet. The Contractor shall provide all labor, tools, equipment, and materials necessary for complete concrete spalling repair of the three (3) 2-story structures located at 817, 818, and 820 Washington Street, Key West, Florida. Contractor will refer to the construction plans provided in this section of the IFB. Contractor shall conduct operations under the contract in such a manner as to allow, during the performance of the work, ingress and egress for the tenants and other authorized persons with the HA's cooperation. The work shall be conducted efficiently and at the least inconvenience to the residents. The Contractor shall provide all necessary safety equipment, materials, and personnel to protect the public walks and entrances to buildings and grounds within the work areas of the Contract so that pedestrians, tenants, and the public are protected at all times. The Contractor shall protect and be responsible for the existing buildings, facilities, and improvements within the areas of the operations under the Contract. Should any portion of the buildings or areas be damaged due to work of the Contract, the Contractor shall report the conditions and circumstances to the HA and shall make all necessary repairs and replacements to such damaged work at its own expense. The Contractor shall be responsible for any damage or loss incurred because of the work of the Contract to tenant's property or other work, and shall, at its own expense, replace any material which, in the opinion of the HA, has become damaged to such extent that it cannot be restored to its original condition. All work shall be done in a neat clean manner by experienced and capable persons. The Contractor shall keep the premises free of debris and construction materials resulting from the work. All debris and such materials shall be removed from the premises at the end of each workday. Upon completion of the work, the Contractor shall assume ownership of all debris resulting from the work, remove it from the premises, and legally dispose of it, unless otherwise specified. The work shall be conducted Monday through Friday, between the hours of 8:00 a.m. and 5:00 p.m. No work shall be conducted on weekends or Federal holidays. The work shall be completed within the time schedule established in the notice to proceed issued by the Contracting Officer. If the Contractor fails to complete the work within the time period established in the notice to proceed, the Contractor shall pay to the HA as liquidated damages the sum of $100.00 for each day of delay.
.webp)
