Site work for a playground / park / athletic field in Carrabelle, Florida. Completed plans call for site work for a playground / park / athletic field.

Pursuant to the regulations found at 2 Code of Federal Regulations (CFR), Part 200 at seq., in addition to the statutory authority requirements and program atic guidance governing the Federal Emergency Management Agency (FEMA) Disaster Recovery Programs the Franklin County Board of County Commissioners will receive sealed bids from any qualified person, company or corporation interested in constructing. Project s Description: Performing FEMA funded repairs to Island View Park which consist of asphalt concrete grading, dock work, etc. Island View Park is located approximately 1.8 miles east of Carrabelle, Florida. Completion date for this project will be 90 days from the date of the Notice to Proceed presented to the successful bidder. Liquidated damages for failure to complete the project on the specified date will be set at $250.00 per day. Please indicate on the envelope that this is a sealed bid, for Franklin County Island View Park Repairs . The Board of County Commissioners reserves the right to waive informalities in any bid, to accept and/or reject any or all bids, and to accept the bid that in their judgment will be in the best interest of Franklin County. All bids shall remain firm for a period of sixty days after the opening. All bidders shall comply with all applicable State and local laws concerning licensing registration and regulation of contractors doing business to the State of Florida. Franklin County encourages Minority Business Enterprises to respond to this Bid Invitation. If you have any questions, please call Erin Griffith at (850) 653-9783 Ext.158. All technical questions must be addressed in writing and emailed to Erin Griffith at erin@franklincountyflorida.com no later than March 25th, 2022.