Renovation of an educational facility in Auburn, Alabama. Completed plans call for the renovation of a educational facility.

Scope of Work: The Work is required to be completed in two Phases. The work will include, but is not limited to Selective Demolition, new flooring, new windows, new HVAC units, new eave extensions with new metal soffits and new standing seam metal roofing. A cashier's check or bid bond payable to Auburn city Schools in an amount not less than five (5) percent of the amount of the bid, but in no event more than $10,000, must accompany the bidder's proposal. Performance and Payment Bonds and evidence of insurance required in the bid documents will be required at the signing of the Contract. All bidders bidding in amounts exceeding that established by the State Licensing Board for General Contractors must be licensed under the provisions of Title 34, Chapter 8, Code of Alabama, 1975, and must show evidence of license under the provision of Title 34, Chapter 8, Code of Alabama, 1975, and must show evidence of license before bidding or bid will not be received or considered by the Architect (Engineer); the bidder shall show such evidence by clearly displaying his or her current license number on the outside of the sealed envelope in which the proposal is delivered. The Owner reserves the right to reject any or all proposals and to waive technical errors if, in the Owner's judgment, the best interests of the Owner will thereby be promoted. The project is being bid EXCLUDING SALES TAXES and requires the Contractor to comply with the requirements of Act 2013-205 which was signed into law on May 19, 2013. The Contractor and Owner will be required to apply for Certificates of Exemption with the Alabama Department of Revenue which will handle administration of the Certificates. The Contractor shall account for the tax savings on the Accounting of Sales Tax ABC Form C-3A-Sales Tax form included in the Specifications behind the Proposal form. Failure of the Contractor to complete this form and include with their Proposal shall render the bid non-responsive. The Contractor shall be responsible for paying the Division of Construction Management's Permit Fee for construction. The Fee Calculation sheet is included in the Project Manual or contractors may visit the Division of Construction Management website to calculate the fee to be included in bid. Performance Time: The overall project must be completed on, or before July 31, 2023. The anticipated "Notice to Proceed" is May 31, 2022. Prospective bidders need to see the Construction Documents for additional information on the required completion dates of intermediate phases.