Site work and paving for a road / highway in Pensacola, Florida. Completed plans call for site work for a road / highway; and for paving for a road / highway.

Award Details Contract Award Date: Apr 08, 2022 Contract Award Number: 140P5222P0030 Task/Delivery Order Number: Contractor Awarded Unique Entity ID: FNRMNJNCWKG4 Contractor Awarded Name: PLUMBING SHOP, INC. , THE Contractor Awarded Address: Austell, GA 30168-6109 USA Base and All Options Value (Total Contract Value): $89066.43 FIRM-FIXED PRICE CONSTRUCTION CONTRACT to perform Pavement Preservation at multiple sites within Gulf Islands National Seashore GULF ISLANDS NATIONAL SEAHORE, Fort Barrancas/Advance Redoubt Areas on board Naval Air Station (NAS) Pensacola in NW Florida SCOPE: The Contractor shall provide all labor, tools, equipment, materials and supervision to complete Work under proposed Firm-Fixed Price construction contract: LI 10: Fort Barrancas Entrance Trail/Parking Area (~ 21,942 SF) Clean and seal existing cracks BEFORE Asphalt Surface Sealer Application Apply Thermoplastic Line Striping and Pavement Markings LI 20: Advanced Redoubt Road and Parking Area (~ 2100 SF) Clean and prep pavement surface Cut, remove and repair depression (~20' x 20') Mill transition at Taylor Road entrance Tack coat application 2" overlay 12.5 asphalt mix Shoulder support Remove old Parking Blocks and dispose offsite Replace new Parking Blocks at handicap parking space(s) Apply Thermoplastic Line Striping and Pavement Markings MAGNITUDE: A firm fixed price construction contract with an estimated price range between $100,000 and $250,000. The Contractor shall be required to (a) commence work under this contract within 5 calendar days after the date the Contractor receives the notice to proceed, (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than 4 MAR 2022 (150 Days after NTP). The time stated for completion shall include final cleanup of the premises. The completion date is based on the assumption that the successful offeror will receive the notice to proceed by 15 SEP 2021. The completion date will be extended by the number of calendar days after the above date that the Contractor receives the notice to proceed, except to the extent that the delay in issuance of the notice to proceed results from the failure of the Contractor to execute the contract and give the required performance and payment bonds within the time specified in the offer. (End of clause) * The Contracting Officer shall specify either a number of days after the date the contractor receives the notice to proceed, or a calendar date. An organized site visit has been scheduled for - WED, 23 MAR 2022 9 AM (c) Participants will meet at - Fort Barrancas Area, 3182 Taylor Road - VC Parking Lot on board NAVAL AIR STATION PENSACOLA enter the installation via the West Gate (Blue Angel Parkway). Visitor's pass obtain from the Visitors Control Center (VCC) Bldg. 777 will require federal employee or military member escort Request for clarifications of the technical requirements may be submitted on or before 28 MAR 2022. BASIS OF AWARD: Comparative evaluation of quotation or offer using price and past performance (relevant and recent past 5 years. Period of Performance: 05/02/2022 to 07/01/2022 Fort Barrancus Entrance Trail PMIS 188258 PEPC 40422 R5323220010 TASK: Pavement Preservation SURFACE AREA: Estimated 21,942 SF Clean and seal cracks before asphalt surface sealer application Requisition No: 0040562614 *The value for this project is based on a financial range. The value is listed as the highest possible cost from the range provided by a stakeholder or official project document. Goals for minority participation for each trade 18.3% Goals for female participation for each trade 6.9%