Site work and paving for a road / highway in Plainfield charter Township, Michigan. Completed plans call for site work for a road / highway; and for paving for a road / highway.

This work consists of electing to furnish low-tracking bond coat emulsified asphalt in lieu of standard bond coat. Ensure all work is in accordance with section 904 of the Standard Specifications for Construction and applicable special provisions, except as modified herein. The low-tracking bond coat emulsified asphalt must conform to approved acceptance test methods and procedures described in the Materials Quality Assurance Procedures Manual. No deviations to acceptance test methods and procedures will be allowed. The undersigned encloses a bid bond in the amount of five (5) percent payable to Kent County Road Commission as a guarantee of good faith. If the undersigned is the successful respondent and fails to enter into a contract or to furnish satisfactory bonds and certificates of insurance to the Board of County Road Commissioners within seven days after being furnished with the necessary contract, said bond shall be forfeited to the County of Kent as liquidated damages. The successful respondent shall furnish the Contracting Board with a Performance Bond in the amount of the Total Contract within seven (5) consecutive days of date of award by said Board before Contract can be executed. This contract cannot begin before Monday, May 2, 2022. A preconstruction meeting shall be held before any work begins to determine a schedule. The contractor may not work over the Memorial Day or 4th of July, holiday periods. If these holidays fall within the contractors work schedule, the contractor shall make sure there is at least a base course of pavement on everything disturbed and that the area is clean and safe for the general public. The completion date for this project is August 31, 2022. The HMA Leveling Mixture____HMA,3C____shall have a yield of ___220_____pounds per square yard. The Performance Grade asphalt binder range shall be ___64-28___. The HMA Surface Mixture ___HMA, 5EML_______ shall have a yield of ___ 165___pounds per square yard. The Performance Grade asphalt binder range shall be __64-28__. (Tier 1) The HMA Surface Mixture ___HMA, 5EML_______ shall have a yield of ___ 165___pounds per square yard. The Performance Grade asphalt binder range shall be __64-22__. (Tier 2) The Board reserves the right to reject any and all Proposals or to waive irregularities therein, and to accept any Proposals which, in the opinion of the Board, may be most advantageous and to the best interest of the County. This contract will be considered for award on April 12, 2022.