Renovation of an educational facility in Huntsville, Alabama. Completed plans call for the renovation of a educational facility.

UAH Materials Science (MSB) Roof Replacement Project A cashier's check or bid bond (DCM Form C-4) payable to The University of Alabama in Huntsville in an amount not less than five (5) percent of the amount of the bid, but in no event more than $10,000, must accompany the bidder's proposal. Performance and Payment Bonds and evidence of insurance required in the bid documents will be required at the signing of the Contract. Drawings and specifications may be examined at the office of Fuqua & Partners Architects, P.C., 100 Church Street, Suite 700, Huntsville, AL 35801. Written prequalification procedures and criteria are available for reviewat the office of Fuqua & Partners Architects, P.C., 100 Church Street, Suite 700, Huntsville, AL 35801. Bids must be submitted on proposal forms furnished by the Architect (Engineer) or copies thereof. All bidders bidding in amounts exceeding that established by the State Licensing Board for General Contractors must be licensed under the provisions of Title 34, Chapter 8, Code of Alabama, 1975, and must show evidence of license before bidding or bid will not be received or considered by the Architect (Engineer); the bidder shall show such evidence by clearly displaying his or her current license number on the outside of the sealed envelope in which the proposal is delivered. The Owner reserves the right to reject any or all proposals and to waive technical errors if, in the Owner's judgment, the best interests of the Owner will thereby be promoted. Notice of Sales & Use Tax Exemption: Materials incorporated into the Work are exempt from sales and use tax pursuant to Alabama Act No. 2013-205 (effective October 01, 2013). The contractor and their subcontractors shall be responsible for complying with rules and regulations of the Sales, Use, and Business Tax Division of the Alabama Department of Revenue regarding certificates and other qualifications to claim such exemption when making qualifying purchases from vendors. The Owner shall not consider claims for additional costs resultant of the contractor's, or their subcontractor's, failure to comply with such rules and regulations. Alabama Law (Section 41-4-116, Code of Alabama 1975) provides that every bid submitted and contract executed shall contain a certification that the vendor, contractor, and all of its affiliates that make sales for delivery into Alabama or leases for use in Alabama are registered, collecting, and remitting Alabama state and local sales, use, and/or lease tax on all taxable sales and leases into Alabama Alabama Immigration Law (Act 2011-535 and codified in state law as Title 31, Chapter 13 of the Code of Alabama 1975, amended by Act No. 2012-491) requires the University to require all Contractors to enroll in the E-Verify program and to provide documentation of enrollment in the EVerify program with their contracts or agreements. This is applicable to all General Contractors and Subcontractors performing work on a University project. Nonresident bidders must accompany any written bid documents with a written opinion of an attorney at law licensed to practice law in such nonresident bidder's state of domicile, as to the preferences, if any or none, granted by the law of that state to its own business entities whose principal places of business are in that state in the letting of any or all public contracts. Completion Date: 120 Calendar days.