Renovation of a mixed-use development in Donna, Texas. Completed plans call for the renovation of a educational facility.

As of 3/10/2023, this project has been awarded but the award amount was not confirmed. All questions regarding the scope of work must be e-mailed to Luis Solis, Safety Representative Project Manager at lsolis2@donnaisd.net. Proposals received after the deadline will be rejected. All proposals which are in order and properly signed shall be opened and reviewed. No immediate decisions shall be rendered concerning the submitted proposals. Donna Independent School District reserves the right to reject any and all proposals. To be considered, the qualifications shall include one (1) original and two (2) copies of the proposals in a sealed envelope, which clearly identifies the RFP number/title as well as the Respondent's name and return address. The District cautions respondent to ensure actual delivery and receipt of mailed or hand-delivered proposals to the District, at the address above, prior to the response deadline. The District will in no way be responsible for delays caused by any occurrence. The successful bidder(s)/proposer(s) will be notified in writing (manifested by an award letter or properly executed purchase order) after review and acceptance by the Donna ISD. The District cautions respondent to ensure actual delivery and receipt of mailed or hand-delivered proposals to the District, at the address above, prior to the response deadline. The District will in no way be responsible for delays caused by any occurrence. Contractor does hereby agree, as a part consideration of the awarding of this Contract, to pay the Owner the amount of FIVE HUNDRED DOLLARS ($500.00) not as a penalty but as liquidated damages All questions regarding the scope of work must be e-mailed to Luis Solis, Safety Representative Project Manager at lsolis2@donnaisd.net.