Renovation of a municipal facility in Garner, Iowa. Completed plans call for the renovation of a municipal facility.

The work for the project shall be accomplished under a Single Construction Contract and there will be a Single Bid to include all of the following: 1. General Construction. 2. Mechanical Construction, including: Plumbing and Ventilating. 3. Electrical Construction, including: Power and Lighting. On-site mobilization and construction shall begin no sooner than July 17, 2023. The Owner requires substantial completion for the project by October 15, 2023 (dependent upon material delivery lead times) These Documents may be obtained after the aforementioned date by Prime Contractors upon request to the Architect and on the condition they be returned after the receipt of bids. There will be no Contract Document deposit. All bids shall be on the basis of cash payment for the work. Form of Contract to be used will be Form of Contract to be used will be "The Standard Form of Agreement between Owner and Contractor, where the basis for payment is a Stipulated Sum", issued by the American Institute of Architects, AIA Document A101-2017. Each Bid shall be accompanied by Bid Security, in a separate sealed envelope, in the form of either (1) cash, cashiers check or certified check or certified share draft drawing on a credit union in Iowa or chartered under the laws of the United States, in an amount equal to at least Five (5%) Percent of Project Bid Amount or (2) a Bid Bond executed by a corporation authorized to contract as a surety in the State of Iowa with the amount or penal sum of not less than Five(5%) Percent of Project Bid Amount. The bid security should be made pay able to the City of Garner. Such bid security shall be forfeited to the City of Garner as liquidated damages in the event the successful bidder fails or refuses to enter into a Contract within ten(10) days after the Award of Contract and post bond satisfactory to said owner insuring the faithful fulfillment of the Contract pursuant to the provisions of this Notice and the other Contract Documents. No bidder may withdraw their bid for at least thirty (30) days after the scheduled closing time for the receipt of bids. The City of Garner, Iowa reserves the right to reject any or all bids and waive all informality and irregularity in connection therewith if the same is judged to be in their best interests, and to make a selection, including that of any Alternate Bids, that in their judgment is best suited for the purpose intended for the project.