Renovation of a municipal facility in Kansas City, Missouri. Completed plans call for the renovation of a municipal facility.

Construction Services for exterior improvements at the Jackson County, Missouri downtown Courthouse Questions Due Date Jun 20th 2023, 5:00 PM CDT Project Location: Jackson County Courthouse, 415 East 12th Street, Kansas City, Missouri 64106. All construction renovations for this Project must be installed within One Hundred Ninety (190) Working Days. This project will be inspected and managed by the Jackson County, Missouri Department of Public Works. Contacts for the Public Works Department will be furnished upon award of project. If Bidder is not located in the Greater Kansas City Metropolitan Area, Bidder MUST provide detailed information with their bid on how the Specifications of this Invitation to Bid will be performed. Jackson County, Missouri reserves the right to determine if Bidder's plan if acceptable. This information can be on Bidder's letterhead and uploaded with your bid documents. Bid Bond in the amount of five percent (5%) of the total bid amount must be turned in to the Purchasing Department, Jackson County, Missouri Courthouse, 415 East 12th Street, Ground Floor, Room G-1, Kansas City, Missouri 64106 before the Response Deadline for this Invitation to Bid. Bid Bond can also be uploaded with your bid documents, but the hard copy must be delivered to the Purchasing Department within five (5) business days after Response Deadline. Time of Completion: The time of completion is of the essence on this project and it will be necessary for the Bidder to provide to the County proof their ability to complete the project by the deadline set in Item No. 1.6 in Section 1.0 Introduction. Information detailing how Bidder will meet this deadline must be submitted with your bid. Attention is directed to Public Works General Conditions, Section 48 "EXTENSION OF TIME" and Section 49 "LIQUIDATED DAMAGES" and Special Conditions, Section 48 "EXTENSION OF TIME" and Section 49 "LIQUIDATED DAMAGES", relative to delays, extensions of time and liquidated damages. Time of Completion information can be on Bidder's letterhead and uploaded with your bid documents. Performance and Labor and Materials Bond Required: The Successful Bidder will be required to submit to the Purchasing Department a Performance Bond and Labor and Materials Payment Bond in the amount of 100% of the contract award within ten business days after Notification of Award. Maintenance Bond Required: The Successful Respondent shall be required to submit a Maintenance Bond on the work being performed for a Two-Year Maintenance Period. The bond must be in a form acceptable to the Director of Finance and Purchasing, executed by a Surety Company authorized to do business in the State of Missouri and listed on the Federal Register. Contractor shall submit a Maintenance Bond to Jackson County Public Works (JCPW) upon the Final Acceptance by the County.