Site work and paving for a mixed-use development in Rancho Cordova, California. Completed plans call for site work for a road / highway; for paving for a road / highway; sidewalk / parking lot; and sidewalk / parking lot.

Remove and replace PCC curb, gutter, sidewalk, and sidewalk ramps at various locations in the City of Rancho Cordova. General Engineering Contractor, Class A or C-8 Concrete Contractor Each bid must be submitted on the bid forms provided in the Contract Documents. Each bid must also be accompanied by security in the form of a bid bond issued by a corporate surety, a certified check or cashier's check payable to the City of Rancho Cordova, or cash for an amount not less than ten percent (10%) of the aggregate sum of the bid. The successful bidder shall be required to execute a Material and Labor Payment Bond and Performance Bond, issued by a corporate surety, acceptable to the City of Rancho Cordova, each for not less than one hundred percent (100%) of the contract price. Time for completion of the base bid work is 50 working days from the date of issuance of the Notice to Proceed by the City. The City of Rancho Cordova reserves the right to reject any or all bids, to waive any informality in any bid, and to determine which bid, in their judgment, is the lowest responsive bid of a responsible bidder. Engineer's Estimate: $ 210,000.00 Contact Ben Chan for more information (916) 851-8873 bchan@cityofranchocordova.org PROJECT DESCRIPTION The work to be done under this contract consists, in general, of furnishing all labor, materials, tools, equipment, incidentals, and for doing all work necessary for removing and replacing concrete curb, gutter, sidewalk, and sidewalk ramps, as well as other items and details not mentioned above but described in the special provisions or shown on the plans or as designated by the engineer. No pre-bid conference or walk-through will be held for the purpose of reviewing and answering questions regarding this Project. Any interested contractor or his/her agent may contact Ben Chan at (916) 851-8873 for specific questions regarding this project. The City of Rancho Cordova's policy goal of the MBE/WBE Programs is to assure that minority business enterprises (MBE) and woman business enterprises (WBE) are given the opportunity to participate in contract and procurement for supplies, construction, equipment and services under any EPA grant or cooperative agreement. Use of MBE/WBE's is recommended as part of this project. Award of this contract requires a valid California contractor's license with the classification identified abov Any questions or assistance obtaining the Bid Proposal forms can contact the City of Rancho Cordova City Hall, 2729 Prospect Park Drive, Rancho Cordova, CA 95670 or telephone Ben Chan (916) 851-8873 between the hours of 9:00 a.m. - 4:45 p.m. Monday through Friday. The County of Sacramento Standard Construction Specifications, which are incorporated by reference in the Contract Documents, are also on sale at the County of Sacramento Municipal Services Agency, Technical Resources Section, 827 7th Street, Room 105, Sacramento, CA 95814. As set forth in Section 8-10, "Liquidated Damages for Delay," of the Standard Construction Specifications, the liquidated damages for this contract shall be the sum of One Thousand Five Hundred Dollars ($1,500) for each and every calendar day beyond the number of working days plus any extensions of time as set forth in Section 7-18, "Extension of Time," of the Standard Construction Specifications.