Site work and paving for a civil project in Carrabelle, Florida. Completed plans call for site work for a road / highway; for paving for a road / highway; and water / sewer project.

The Franklin County Board of County Commissioners will receive sealed bids from any qualified person, company or corporation interested in constructing: CR 67 PHASE III WIDENING AND RESURFACING PROJECT The project is the widening and resurfacing of County Road 67 for approximately 1.79 miles from State Forest Road 166 to State Forest Road 172. Other work to include necessary drainage improvements, upgraded signage and pavement markings and safety improvements. All bidders shall be FDOT qualified per Section 2-1 of the FDOT Standard Specifications for Road and Bridge Constructions, latest edition in the following work classes: Grading, Drainage, Flexible Paving, and Hot Plant Mix-Bituminous Course. Completion date for this project will be 150 days from the date of the Notice to Proceed presented to the successful bidder. Liquidated damages for failure to complete the project on the specified date will be set at $750.00 per day. The Board of County Commissioners reserves the right to waive informalities in any bid, to accept and/or reject any or all bids, and to accept the bid that in their judgment will be in the best interest of Franklin County. All bids shall remain firm for a period of sixty days after the opening. All bidders shall comply with all applicable State and local laws concerning licensing registration and regulation of contractors doing business to the State of Florida. Question Deadline 02/23/2024 at 5:00 PM ET. All technical questions must be addressed in writing and emailed to Caleb Brown at cbrown@dewberry.com