Site work and paving for a civil project in Port St Joe, Florida. Completed plans call for site work for a road / highway; for paving for a road / highway; and water / sewer project.

As of April 25, 2024 obtained the the apparent lowest bidder Roberts & Roberts with the amount of $2,713,414.24 This project includes approximately 5.80 miles of roadway resurfacing including storm water improvements in the Overstreet Community in Gulf County, FL. All bidders shall be FDOT Qualified per Section 2-1 of the FDOT Standard Specifications for Road and Bridge Construction, latest edition in the following work classes: Grading, Drainage, Flexible Paving, and Hot Plant Mix-Bituminous Course. The completion date for this project will be 120 days from the date of the Notice to Proceed presented to the successful bidder. Liquidated damages for failure to complete the project on the specified date will be set at $2,650.00 per day. All questions must be submitted to Clay Smallwood, P.E. at csmallwood@gulfcounty-fl.gov. Please place Your Company name, Sealed bid, and the Bid number on the outside of your envelope and include the original bid plus 2 copies. The Board of County Commissioners reserves the right to waive informalities in any bid, to accept and/or reject any or all bids, and to accept the bid that in their judgment will be in the best interest of Gulf County. Minority and women's business enterprises are hereby solicited to bid on this contract as prime contractors and are encouraged to make inquiries regarding potential subcontracting opportunities and equipment, material and/or supply needs. All bidders must make positive efforts to use small and minority owned business and women business enterprises. This contract will be paid for in whole or in part with Community Development Block Grant - Mitigation Program funding (CDBG-MIT) from the U. S. Department of Housing and Urban Development ("HUD") and the Florida Department of Economic Opportunity ("DEO") for activities authorized under Title I of the Housing and Community Development Act of 1974. As such this contract is subject to the applicable terms and conditions of Subrecipient Agreement MT145 between DEO and the Gulf County Board of County Commissioners, 45 CFR Part 75, 29 CFR Part 95, 2 CFR Part 200 (including Appendix II to Part 200), 20 CFR Part 601, 24 CFR Part 570 subpart I, et seq., and all other applicable State and Federal laws, rules, regulations, and policies governing the funds provided through the Subrecipient Agreement, as now in effect and as may be amended from time to time. The Subrecipient Agreement allocates total funding of $2,624,668.00 (100%) for this project in CDBG-MT funds. The Gulf County Board of County Commissioners is an Equal Opportunity Employer. All bids shall remain firm for a period of sixty days after the opening. All bidders shall comply with all applicable State and local laws concerning licensing registration and regulation of contractors doing business to the State of Florida. The bid must conform to Section 287.133(3) Florida Statutes, on public entity crimes.