Renovation of a residential development in Village of Wellington, Florida. Completed plans call for the renovation of a residential development.

This Rehabilitation Specifications Work Write Up shall be submitted in its entirety. It shall fully disclose the scope of work to be performed, permitted and inspected. The quote must be sealed in an envelope (do not include more than one quote). The face of the envelope shall contain the Village of Wellington Address and the address of the project. Those that do not comply with these condition s are subject to rejection Property Address: 13469 Fountain View Blvd, Wellington, FL 33414 Question Deadline: 02/17/2024, All inquiries must be submitted in writing to Christian Santa- Gonzalez, a minimum of 72 hours prior to the quote opening and allow 2 business days to respond. No interpretation shall be considered binding unless provided to all respondents in writing by Wellington. The proposed work shall be completed within 120 working days. Village of Wellington has allocated a portion of its SHIP entitlement grant to an "Owner-occupied Rehabilitation Program," which provides funds for income qualified homeowners to make necessary repairs to their primary residence. On behalf of the homeowner, The Village of Wellington is requesting quotes from licensed general contractors for the rehabilitation of 13469 Fountain View Blvd, Wellington, FL 33414. : Contractor shall complete the work within 120 working days of issuance of the Notice to Proceed unless a time extension has been requested by the Contractor and agreed to in writing by the Village of Wellington. Contractor and Wellington agree that, because of the nature of the work, the inability of the parties to precisely calculate actual damages for delay, and the difficulty of determining these damages, the Contractor shall pay Wellington the sum of $50.00 per working day of delay. The parties further agree that such sum is not a penalty and not excessive in light of the circumstances known to the parties at the time of award. Wellington reserves the right to amend this request for quotes prior to the opening date indicated. Only written addenda will be binding. If, upon review, material errors in specification are found contact Andrew Stoops immediately at (561) 753-2435 or at astoops@wellingtonfl.gov, prior to the quote opening date, to allow for review and subsequent clarification on the part of Wellington.