Site work and paving for a mixed-use development in Madison, Wisconsin. Completed plans call for site work for a sidewalk / parking lot; for paving for a sidewalk / parking lot; and multi-residential development.

The Contractor shall furnish all necessary labor, material, equipment, and supervision to replace select sidewalks, at the Community Development Authority (CDA) East Truax Park Apartments, 3538 Straubel St #101 Madison WI 53704. Liquidity Damages: Recover on behalf of the City from the prime Contractor 0.5 percent of the Contract award price for each week that such party fails or refuses to comply, in the nature of liquidated damages, but not to exceed a total of five percent (5%) of the Contract price, or ten thousand dollars ($10,000), whichever is less. Under public works contracts, if a subcontractor is in noncompliance, the City may recover liquidated damages from the prime Contractor in the manner described above. The preceding sentence shall not be construed to prohibit a prime Contractor from recovering the amount of such damage from the noncomplying subcontractor. Liquidated damages. The contractor may be charged liquidated damages on an existing contract of two thousand dollars ($2,000) per violation, or an amount equaling twenty percent (20%) of the value of the apparel, garments or corresponding accessories, equipment, materials, or supplies that the City demonstrates were produced in violation of the contract and/or this ordinance per violation; whichever is greater. Recover on behalf of the City from the prime Contractor 0.5 percent of the Contract award price for each week that such party fails or refuses to comply, in the nature of liquidated damages, but not to exceed a total of five percent (5%) of the Contract price, or ten thousand dollars ($10,000), whichever is less. Under public works contracts, if a subcontractor is in noncompliance, the City may recover liquidated damages from the prime Contractor in the manner described above. The preceding sentence shall not be construed to prohibit a prime Contractor from recovering the amount of such damage from the noncomplying. Questions Due Date: February 13, 2024 Answers Posted Date: February 15, 2024 Owner Rights: The City reserves the right to accept or reject any or all Bids submitted, in whole or in part, and to waive any informalities or technicalities, which at the City's discretion is determined to be in the best interests of the City. Further, the City makes no representations that a contract will be awarded to any Bidder responding to this request. The City expressly reserves the right to reject any and all Bids responding to this invitation without indicating any reasons for such rejection(s). The City reserves the right to postpone due dates and openings for its own convenience and to withdraw this solicitation at any time without prior notice. The City reserves the right to waive or permit cure of nonmaterial variances in the offer if, in the judgment of the City, it is in the City's best interest to do so. The determination of materiality is in the sole discretion of the City. The City reserves the right to request usage reports at any time and request additional information, if required, when reviewing contract activity. Prevailing Wage. Where applicable under federal law, the Contractor warrants that prevailing wages will be paid to all trades and occupations. The Secretary of Labor may require the Contractor to set aside in a separate account assets for the meeting of obligations under the plan or program. Questions Due Date: February 13, 2024 Please direct any other questions to the Purchasing contact person below. Tammy Jones City of Madison Purchasing Services PH: (608) 266-4521 tjones@cityofmadison.com