Renovation of a residential development in Village of Wellington, Florida. Completed plans call for the renovation of a residential development.

The Village of Wellington, A Florida Municipal Corporation, hereinafter referred to as Wellington, is an entitlement recipient of State Housing Initiatives Partnership (SHIP) funds established under the 1992 William E. Sadowski Affordable Housing Act. The Village of Wellington has allocated a portion of its SHIP entitlement grant to an "Owner-occupied Rehabilitation Program," which provides funds for income-qualified homeowners to make necessary repairs to their primary residence. On behalf of the homeowner, The Village of Wellington is requesting quotes from licensed general contractors for the rehabilitation of 880 Lantern Tree Lane, Wellington, FL 33414. Wellington reserves the right to amend this request for quotes prior to the opening date indicated Only written addenda will be binding. If, upon review, material errors in specification are found contact Gloria Kelly immediately at (561) 791-4105 or at gkelly@wellingtonfl.gov, prior to the quote opening date, to allow for review and subsequent clarification on the part of Wellington. All inquiries must be submitted in writing to Gloria Kelly, a minimum of 72 hours prior to the quote opening and allow 2 business days to respond. No interpretation shall be considered binding unless provided to all respondents in writing by Wellington. Liquidated Damages: Contractor shall complete the work within 120 working days of issuance of the Notice to Proceed unless a time extension has been requested by the Contractor and agreed to in writing by the Village of Wellington. Contractor and Wellington agree that, because of the nature of the work, the inability of the parties to precisely calculate actual damages for delay, and the difficulty of determining these damages, the Contractor shall pay Wellington the sum of $50.00 per working day of delay. The parties further agree that such sum is not a penalty and not excessive in light of the circumstances known to the parties at the time of award. The proposed work shall be completed within 120 working days. Submittal Due Date: March 28th, 2024 at 4:00 PM Eastern Daylight Time Submittal Opening: March 28th, 2024 at 4:30 PM Eastern Daylight Time