Site work and paving for a mixed-use development in Aberdeen, South Dakota. Completed plans call for site work for a road / highway; for paving for a road / highway; sidewalk / parking lot; and sidewalk / parking lot.

2024 Accessible quadrant improvement project which shall include, but is not limited to: concrete removals, replacement of concrete sidewalk, curb and gutter, asphalt patching, detectable warning panels and appurtenant work. Accessible Quadrant Improvements which shall include, but not be limited to: Concrete removals, replacement of concrete sidewalk, curb and gutter, asphalt patching, detectable warning panels and appurtenant work. Work shall include all labor, equipment, and materials to complete the work in accordance with specifications now on file at the City Finance Office, Auditor Division, and the City Engineering Office, Aberdeen, South Dakota and will be available at no charge from the latter by calling (605) 626-7010. Bond Notes: Each bid in excess of $25,000 shall be accompanied by any one of the following: (1) A certified check, cashier's check, or draft certified or issued by a state or national bank for five per cent (5%) of the amount of the total gross bid; or (2) A bid bond issued by a surety authorized to do business in South Dakota for ten per cent (10%) of the amount of the bid; or (3) An irrevocable letter of credit for one hundred percent (100%) of the amount of the bid from a financing agency of good repute and deemed acceptable to the City of Aberdeen, all in accordance with SDCL Ch. 5-18A and SDCL Ch. 57A-5. The bid security shall be made payable without condition to the City of Aberdeen, South Dakota, hereinafter referred to as Owner. The bid security may be retained by and shall be forfeited to the Owner as liquidated damages if the bid is accepted and a contract based thereon is awarded and the bidder shall fail to enter into a contract in the form prescribed, with legally responsible sureties, within ten (10) days after such award is made by the Owner. Contracts in excess of $25,000 will require a Payment Bond and a Performance Bond acceptable to the Aberdeen City Council, for one hundred percent (100%) of the Contract, in conformance with the requirements of the Contract documents. No bid may be withdrawn within a period of thirty (30) days after the date fixed for opening bids. Owner Rights: The Aberdeen City Council reserves the right to reject any and all bids, waive irregularities and accept the bid it deems most favorable and in the best interest of the City of Aberdeen after all bids have been examined. The Owner reserves the right to accept the bid which, in its judgment, is the lowest and best bid, to reject any or all bids, and to waive irregularities or informalities in any bid. Bids received after the specified time of closing will be returned unopened. Time Of Completion. The time of completion of the work is a basic consideration of the contract, and the construction period named in the Bid Form will be taken into consideration in making the award of the contract. The bidder, however, is cautioned against promising an early completion date only to secure favorable consideration of his bid. It will be necessary that the bidder satisfy the Owner of his ability to complete the work within the stipulated time. In connection, attention is directed to the provisions of the General Conditions and Special Conditions relative to delays, extensions of time, and liquidated damages. The Contractor shall complete the work by June 28, 2024. The Contractor to whom a contract is awarded will be furnished, without cost to him, (5) copies of the specifications and (5) sets of the drawings pertaining to the project. The intent of this project is to install new PCC ADA compatible curb ramps on various intersections throughout'the City of Aberdeen. Appurtenant work may include removing and installing catch basins and curb inlets, storm sewer lateral pipe, and asphalt surfacing. The Engineer may elect to have City Public Works staff install the lateral pipe, asphalt surfacing repair; and in some cases curb inlets. If this work is to be completed by City staff, the Engineer will coordinate with the Contractor to identify the areas, scope, and time frame for the work to be performed.