Site work and paving for a civil project in Toledo, Ohio. Completed plans call for site work for a road / highway; for paving for a road / highway; and water / sewer project.

This project will install approximately 1580-feet of 8-inch diameter waterline to replace existing 6-inch on Maumee Avenue, from Prouty Avenue to Knower Street and an accommodation tap on Prouty Avenue, from Maumee Avenue to dead end. This project will improve 0.25-miles of Maumee and Prouty Avenues through removal of existing wearing course and resurfacing. Bid Bond 5.00% Payment Bond 0.00% Performance Bond 100.00% Q&A Deadline 04/24/2024 2:00 PM (EDT) All questions regarding the plans and specifications must be in writing by through the Planet Bids website. The City s response will be placed on Planet Bids for all potential bidders. This will assure that all potential bidders have the benefit of the same answers to the same questions. If there are questions concerning this notification, please contact: Bureau of Wage and Hour Administration 6606 Tussing Road, PO Box 4009 Reynoldsburg, Ohio 43068-9009 Phone: 614-644-2239 Fax: 614-728-8639 www.com.ohio.gov The City of Toledo reserves the right to reject any, or any part of any, or all bids, to waive technicalities, to advertise for new bids or to make the award if, in the judgment of the City, the best interest of the City will be promoted thereby. Where contracts are not awarded or construction undertaken within ninety days from the date of the establishment of the prevailing wages, there shall be a redetermination of the prevailing rate of wages before the contract is awarded. The expiration date of this wage schedule is listed above for your convenience only. This wage determination is not intended as a blanket determination to be used for all projects during this period without prior approval of this Department. The wage rates contained in this schedule are the Prevailing Wages as defined by Section 4115.03, Ohio Revised Code (the basic hourly rates plus certain fringe benefits). These rates and fringes shall be a minimum to be paid under a contract regulated by Chapter 4115 of the Ohio Revised Code by contractors and subcontractors. The prevailing wage rates contained in this schedule include the effective dates and wage rates currently on file. In cases where future effective dates are not included in this schedule, modifications to the wage schedule will be furnished to the Prevailing Wage Coordinator appointed by the public authority as soon as prevailing wage rates increases are received by this office. The Contractor shall take particular note of contract form provisions, dealing with Time of Performance and Liquidated Damages, which will be used in the determination of resulting damages in the event this contract obligation is not fulfilled by the specified completion date. The quantities specified are estimated and informative only and not a binding offer of purchase on the part of the City. The City of Toledo reserves the right to either increase or decrease the contract quantities Estimated Total Contract price shown on the bidder's Proposal, but no more than $200,000. Project Duration 90 days