Site work and renovation of a mixed-use development in Orlando, Florida. Completed plans call for the renovation of a municipal facility; for site work for a municipal facility; and water / sewer project.

The Estimated Cost for this project is $1,740,000.00 This provision exists solely for the convenience and administrative efficiency of Orange County. No respondent or other third party gains any rights by virtue of this provision or the application thereof, nor shall any respondent or third party have any standing to sue or cause of action arising there from. Question Submission Deadline:May 2, 2024, 5:00pm Untimely questions are unable to be submitted in the question and answer module, thereafter respondents raising critical concerns must email gerson.vazquezgonzalez@ocfl.net. Critical clarifications may be made via addenda, however, untimely questions may not be considered. A Bid, Payment and Performance Bond are a requirement when the offer/contract amount exceeds $100,000. Respondents shall attach an electronic copy of their bid bond for responsiveness. Submission of the bid bond, along with a certified and effectively dated copy of the power of attorney, shall be completed and signed by all required parties and submitted on the form provided in the solicitation. Submittal of a bid bond less than 10% of the total estimated contract amount for base period, shall result in the bid being deemed non-responsive. In the alternative, a Certified Check, or a Cashier's Check shall be required to accompany each electronic offer in a stated dollar amount of not less than ten (10%) percent of the sum of the total estimated contract amount for the base period. Replace existing generators and associated fuel tanks with new. Generators have reached their useful life span and are in need of replacement. Should the Contractor fail to substantially complete all Work under this Contract and make the project available for beneficial use on or before the date stipulated for Substantial Completion (or such later date as may result from extension of time granted by County), he shall pay and/or the County may retain from the compensation otherwise to be paid to the Contractor, as liquidated damages, the sum of $500.00 for each consecutive calendar day that terms of the Contract remain unfulfilled beyond date allowed by the Contract, which sum is agreed upon as a reasonable and proper measure of damages which County will sustain per diem by failure of Contractor to complete work within time as stipulated; it being recognized by County and Contractor that the injury to County which could result from a failure of Contractor to complete on schedule is uncertain and cannot be computed exactly. In no way shall costs for liquidated damages be construed as a penalty on the Contractor. For each consecutive calendar day that the work remains incomplete after the date established for Final Completion, the County will retain from the compensation otherwise to be paid to the Contractor the sum of $500.00. This amount is the mutually agreed upon minimum measure of damages the County will sustain by failure of the Contractor to complete all remedial work, correct deficient work, clean up the project and other miscellaneous tasks as required to complete all Work specified and this amount of liquidated damages is in addition to the liquidated damages prescribed above for failure to timely achieve Substantial Completion. A bid shall constitute an irrevocable offer for a period of one hundred twenty (120) days from the public opening date or until the date of award. In the event that an award is not made by the County within one hundred twenty (120) days from the public opening date, the respondent may withdraw their offer or provide a written extension without modification.