Site work and new construction of an educational facility in Athens, Alabama. Completed plans call for the construction of a educational facility; and for site work for a educational facility.

Limestone Career Technical Center Trainer Structure. Bids Must Be Submitted on Proposal Forms Furnished by the Architect or Copies Thereof. All Bidders Bidding in Amounts Exceeding That Established by the State Licensing Board for General Contractors Must Be Licensed Under the Provisions of Title 34, Chapter 8, Code of Alabama, 1975, and Must Show Evidence of License Before Bidding or Bid Will Not Be Received or Considered by the Architect; the Bidder Shall Show Such Evidence by Clearly Displaying His or Her Current License Number on the Outside of the Sealed Envelope in Which the Proposal is Delivered. Bid Bonds Are to Be Issued by an Acceptable Bonding Company Licensed to Do Business in the State, With a Power of Attorney, to Confess Judgment Thereon, With the Understanding That It Shall Guarantee That the Bidder Shall Not Withdraw His Bid for the Guarantee Period of Sixty (60) Days After the Scheduled closing Time for the Receipt of Bids; That if His Bid is Accepted, He Will Enter Into a Formal Contract With the Owner, and That in the Event of a Withdrawal of Said Bid Within Said Period, or the Failure to Enter Into Said Contract Within the Time Specified, the Bidder Shall Be Liable to the Owner for the Full Amount Ofthe Bid Guarantee as Liquidated Damages and Not as a Forfeit or as a Penalty. A Cashier's Check or Bid Bond Payable to Limestone County Board of Education in an Amount Not Less Than Five (5) Percent of the Amount of the Bid, but in No Event More Than$10,000, Must Accompany the Bidder's Proposal. The Bid bond and Certified Checks on Unsuccessful Bidders Will Be Returned Upon Awarding the Contract or Rejection of All Bids, in No Event, Later Than the Number of Days in the Guarantee Period From the Opening of Proposals. That of the Successful Bidder Will Bereturned When Formal Contract and Bonds Are Accepted and Approved. Bids Must Be Submitted on Proposal Forms Furnished by the Architect or Copies Thereof. All Bidders Bidding in Amounts Exceeding That Established by the State Licensing Board for General Contractors Must Be Licensed Under the Provisions of Title 34, Chapter 8, Code of Alabama, 1975, and Must Show Evidence of License Before Bidding or Bid Will Not Be Received or Considered by the Architect; the Bidder Shall Show Such Evidence by Clearly Displaying His or Her Current License Number on the Outside of the Sealed Envelope in Which the Proposal is Delivered. The Owner Reserves the Right to Reject Any or All Proposals and to Waive Technical Errors if, in the Owner's Judgment, the Best Interests of the Owner Will Thereby Be Promoted.