Site work and new construction of a municipal facility in Sedalia, Colorado. Conceptual plans call for the construction of a municipal facility; and for site work for a municipal facility.

Reference Number 0000353880 Job Location: Sedalia, Colorado 80135 The Department of Facilities, Fleet, and Emergency Support Services (FFESS) of Douglas County Government, hereinafter referred to as the County, respectfully requests bids from responsible, highly-qualified companies for the provision of the construction of the Douglas County Government District 8 Emergency Services Public Safety Complex, as specified, located in Deckers, Colorado. Pre-qualification Requirements and References: All respondents shall meet or exceed the following requirements to be considered as the successful bidder for the construction of this project. Documentation verifying construction experience, as specified below, must be submitted with your bid response. PROJECT DESCRIPTION: The District 8 project located at 10086 SOUTH STATE HIGHWAY 67, SEDALIA, COLORADO 80135, will require the construction of a new metal building and three new bunkhouses for Douglas County. The project scope includes site work related to driveways, septic systems, propane tanks and connections to homes, wells, pumps, retaining walls, utility work, grading, and construction of the new buildings as required to complete a turnkey finished product. The three new homes will be premanufactured, and the General Contractor will have to subcontract the premanufactured home manufacturer. These homes will sit on a foundation basement system that will include a garage space. The General Contractor will also have to subcontract to a metal building supplier. The metal building will consist of an upper-level office space and a lower-level garage space. The structural design of the retaining wall will also be delegated to the General Contractor. Question Deadline 06/12/2024 at 5:00 PM MT Questions are submitted online Yes March 31, 2025 Project Completion Date Buyer Preferences, Guidelines & Requirements General Requirements - FOB Destination - Installation Required - Insurance Required - License Required - Local Service Required - Onsite Maintenance Required - Warranty Information Required Bonding Requirements - Bid Bond 5 % Douglas County Government reserves the right to reject any or all bids, to waive formalities, informalities, or irregularities contained in a said bid and furthermore, to award a contract for items herein, either in whole or in part, if it is deemed to be in the best interest of the County to do so. PROJECT DESCRIPTION A. This project will construct a new metal building and three new bunkhouses for Douglas County. The scope of the project includes site work related to driveways, septic systems, propane tanks and connections to homes, wells, pumps, retaining walls, utility work, grading, and construction of the new buildings as required to complete a turn key finished product. The three new homes will be premanufactured the general contractor will have to subcontract the premanufactured home manufacturer. These homes will sit on a foundation basement system that will include a garage space. The general contractor will have to also subcontract to a metal building supplier. The metal building will consist of an upper-level office space and a lower-level garage space. The retaining wall structural design will also be delegated to the general contractor. See the alternate specification 012300 and the unit prices specification 012200 for more information. B. The design for the pre manufactured home is by Champion Home Builders, Inc. The model number is 6334-MP-STD. There is not room on site for a larger manufactured home. If thegeneral contractor proposes a different model number or manufacturer it will have to be preapproved by the county and the cost difference will have to be noted on the bid form. C. The natural gas provider for the Owner is Spring Valley Gas. Please contact Jessica Walker at 303-660-8810 or jwalker@springvalleygas.com for a quote to do the work shown on the plans.