Demolition and site work for a water / sewer project in Corpus Christi, Texas. Completed plans call for the demolition of a water / sewer project; and for site work for a water / sewer project.

As of August 29, 2024, this project has not yet been awarded. A timeline for award has not yet been established. Morgan Elevated Storage Tank Demolition. Liquidated Damages Owner and Contractor also recognize the delays, expense, and difficulties involved in proving in a legal or arbitration proceeding the actual loss suffered by Owner if the Work is not completed on time. Accordingly, instead of requiring any such proof, Owner and Contractor agree that as liquidated damages for delay (but not as a penalty) Question Deadline 07/17/2024 at 5:00 PM CT. It is the responsibility of the Contractor bidding the project to ensure the accuracy of the reproduction of all Bid Documents and Construction Drawings. This includes, but is not limited to, proper scaling, paper width and length, etc. Failure to do so may result in errors in the Unit Bid Quantities and or Bids Amounts. Bidders must submit an acceptable Bid Security with their Bid as a guarantee that the Bidder will enter into a contract for the Project with the Owner within 10 days of Notice of Award of the Contract. The security must be payable to the City of Corpus Christi, Texas in the amount of 5 percent (5%) of the greatest amount bid. Bid Security may be in the form of a Bid Bond or a cashier's check, certified check, money order, or bank draft from a chartered financial institution authorized to operate in the State of Texas. Estimate: $330,000. Scope There is no planned site visit. Project Scope includes decommissioning and demolition of the Morgan Elevated Storage Tank to include the disposal of the abandoned storage tank, tank foundation, connected waterlines, and all electrical components. The project scope of work includes: Demolition and removal of Morgan Elevated Storage Tank Removal of 12" tank influent and effluent waterline All other site restoration, and yard piping and electrical component removal work included in the Contract Documents Other work shown, specified, or required for a complete demolition. Refer to contract documents, plans, and specifications for additional information. The work is to be substantially completed within 60 days. Bidders are advised to refer to Request for Bids Section 5 of the bidding documents for a list of required bid submittals. Failure to submit or upload all required documents may result in an irregular or non-responsive bid submittal. Until award of the Contract is made by the City, the City reserves the right to reject any or all bids, to waive technicalities, to re-advertise for new bids or to proceed with the work in any manner as may be considered in the best interest of the City. Owner and Contractor also recognize the delays, expense, and difficulties involved in proving in a legal or arbitration proceeding the actual loss suffered by Owner if the Work is not completed on time. Accordingly, instead of requiring any such proof, Owner and Contractor agree that as liquidated damages for delay (but not as a penalty) Perform the Work as required to complete the entire Project within the Contract Times and in the sequence stipulated below: 1. Demolish existing elevated storage tank and perform site work for the 0.5 Morgan Elevated Storage Tank.