Site work and new construction of a mixed-use development in East Brewton, Alabama. Completed plans call for the construction of a educational facility; for site work for a educational facility; theater / auditorium; and theater / auditorium.

General Contractors are required to prequalify prior to requesting Bid Documents. Prequalification proposal requirements may be obtained from the Architect, by request either by phone (205) 345-6110 or e-mail: cbaker@wardscottmorris.com, to Christy Baker. Return one (1) online copy of the completed packet to cbaker@wardscottmorris.com before 5:00pm, legally prevailing time, on July 1, 2024. A written list of Contractors receiving prequalification to bid this project will be issued to all who requested consideration on July 3, 2024. A cashier's check or bid bond payable to Escambia County Board of Education in an amount not less than five (5) percent of the amount of the bid, but in no event more than $10,000, must accompany the bidder's proposal. Performance and Payment Bonds and evidence of insurance required in the bid documents will be required at the signing of the Contract. Bid bonds are to be issued by an acceptable bonding company licensed to do business in the State, with a Power of Attorney, to confess judgment thereon, with the understanding that it shall guarantee that the bidder shall not withdraw his bid for the guarantee period of sixty (60) days after the scheduled closing time for the receipt of bids; that if his bid is accepted, he will enter into a formal contract with the Owner, and that in the event of a withdrawal of said bid within said period, or the failure to enter into said contract within the time specified, the bidder shall be liable to the Owner for the full amount of the bid guarantee as liquidated damages and not as a forfeit or as a penalty. Document notes : of bid date. Other sets for contractors, and sets for dealers, may be obtained with the same deposit, which will be refunded as above, less cost of printing, reproduction, handling, and distribution. Electronic PDF bid documents are available for download from the same website free of charge. The bid bond and certified checks on unsuccessful bidders will be returned upon awarding the contract or rejection of all bids, in no event, later than the number of days in the guarantee period from the opening of proposals. The Owner reserves the right to reject any or all proposals and to waive technical errors if, in the Owner's judgment, the best interests of the Owner will thereby be promoted. Any questions concerning the pre-bid conference shall be directed to the Architect.