Lake county, florida seeks competitive sealed submissions to furnish generator and automatic transfer switch (ATS) Contractor to replace the generator and automatic transfer switch (ATS) at five site Site Preparation
1. Coordinate and obtain any permits required and coordinate any inspections with local authorities that may be needed for component replacement work.
2. Provide engineering services for site drawings of new equipment necessary for any permitting.
3. Provide one time mobilization costs for the construction crews. Any remobilization due to interruptions/delays that are out of the Contractor's control will result in additional costs.
4. Contractor will be responsible for any installation or upgrades for code compliance, as applicable.
5. Provide Turnkey services for complete de-installation, installation, and operation.
6. Confirm all assumptions listed are correct for complete installation. Award Recommended Vendor (ARV) shall execute and deliver to County a Performance and Payment Bond in an amount representing 100% of Contract price. The County's Performance and Payment Bond Form shall be the only acceptable form. Completed form must be delivered to County within fifteen (15) calendar days after formal notice of award. Failure to deliver the Performance and Payment Bond as directed will result in ARV being declared in default of contractual terms and conditions. ARV shall surrender the associated proposal bond (if any). No bid submissions will be accepted from ARV for the following twelve (12) month period. Contract will commence upon the related Notice to Proceed. Contract remains in effect until completion of the expressed and implied warranty periods. County reserves the right to negotiate for additional services/items similar in nature not known at time of solicitation. Contracting Officer
William Ponko
bill.ponko@lakecountyfl.gov
(352) 343-9489
.webp)
