Site work and paving for a mixed-use development in Marina, California. Completed plans call for site work for a road / highway; for paving for a road / highway; sidewalk / parking lot; and sidewalk / parking lot.

The scope of work for this project includes demolition and removal of the existing roadway section; constructing existing roadway with new structure pavement section, constructing concrete curb ramps; and installing bulb-out. Work also include extensive roadway excavation; remove and reconstruct concrete curb ramps, concrete curb and gutter, install new pavement marking, traffic striping and signing, and performing other items or details not mentioned above that are required by the plans, and as specified in the Standard Specifications or these Special Provisions. The Contractor shall perform all work necessary to complete the improvements in their entirety in accordance with the Contract Documents. Time for Completion - All work under this contract shall be completed before the expiration of one hundred and ninety-five (195) working days from the date specified in the Notice to Proceed. If Contractor shall be delayed in the work by the acts or neglect of Owner, or its employees or those under it by contract or otherwise, or by changes ordered in the work, or by strikes, lockouts by others, fire, unusual delay in transportation, unavoidable casualties or any causes beyond the Contractor's control, or by delay authorized by the Owner, or by any cause which the Owner shall decide to justify the delay, then the time of completion shall be extended for such reasonable time as the Owner may decide. Liquidated damages amount per working day shall be as specified in the Special Provisions. All Federal holidays and City holidays observed during construction shall not be included on the construction timeline specified. Time extension for weather and City delays will be granted accordingly. At the time of the bid opening, the successful Bidder must be legally entitled to perform contracts requiring a Class A Contractor's license. Any Bidder or contractor not so licensed shall be subject to all penalties imposed by law including, but not limited to, any appropriate disciplinary action by the Contractors' State License Board. Bid results and inquiries may be obtained from the City of Marina at (831) 884-1212 or email Edrie Delos Santos at edrie@cityofmarina.org or Michaelle Mowery, mmowery@cityofmarina.org. Responses to all inquiries shall be sent out through email or if necessary, bids will be available for inspection by appointment only. This contract may also be used to provide unforeseen conditions repairs upon short notice. Emergency situations may require excavating and working in trenches five (5) feet and over in depth. In order to ensure the safety of such operations, the successful Bidder must provide evidence of a current Cal/OSHA T-1 trenching and excavation permit five days after bid opening. The T-1 permit requirement applies to the Bidder and listing a subcontractor that possesses a T-1 permit in lieu of the Bidder does not fulfill the requirement. This Contract will be subject to compliance monitoring and enforcement by the California Department of Industrial Relations, pursuant to Labor Code section 1771.4. Under California Labor Code section 1771. 1, as amended by SB 854, a contractor may not bid, nor be listed as a subcontractor, for any bid proposal submitted for a public work unless the contractor and its subcontractors are registered and qualified to perform public work pursuant to section 1725.5 of the Labor Code. The Bidder and its Subcontractors must be registered and qualified to perform public work pursuant to section 1725.5 of the Labor Code, subject to limited legal exceptions under Labor Code section 1771. 1. Attention of bidders is called to the fact that effective January 1, 1977, the Director of the State Department of Industrial Relations is required to determine the general prevailing rate of minimum wages to be paid to the various craftsmen and laborers required to construct said improvements. The City Council is cognizant of the prevailing rate of per diem rates and the general prevailing rate for holiday and overtime work in the locality in which the public work is to be performed for each craft, classification or type of workman needed to execute this contract and has made this information a part of the Specifications and Contract for said work by reference thereto. The City Council reserves the right to reject any or all bids and to determine which proposal is, in its judgement, the most responsive bid of a responsible bidder and which proposal should be accepted in the best interest of the City Council. The City Council also reserves the right to waive any informality in any proposal or bid. Proposals received after the time announced for the opening will not be considered. No bidder may withdraw his bid after the time announced for the opening, or before the aware and execution of the contract, unless the award is delayed for a period exceeding ninety (90) days. No telegraphic proposals will be accepted. Contract award will be made to the lowest responsive and responsible bidder based on Grand Total Bid (Base Bid + Bid Additive 1A + Bid Additive 1B). The Engineer shall decide all questions which may arise as to the quality or acceptability of materials furnished and work performed and as to the manner of performance and rate of progress of work, all questions which arise as to the interpretation of these Plans and Specifications, all questions as to the acceptable fulfillment of the contract on the part of the Contractor and all questions as to compensation. His decision shall be final and he shall have authority to enforce and make effective such decisions and orders which the Contractor fails to carry out promptly. *The value for this project is based on a financial range. The value is listed as the highest possible cost from the range provided by a stakeholder or official project document.