Site work for a water / sewer project in Fellsmere, Florida. Conceptual plans call for site work for a water / sewer project.

All bids shall be submitted on the Bid Proposal forms provided in the Specifications. Bid security in the amount of five percent (5%) of the bid must accompany the sealed proposal of each builder will be required as follows: a cashiers check, a certified check, or a surety bond payable to the City of Fellsmere. Deposits will be returned to unsuccessful bidders. If the Contract is awarded to a Bidder, that Bidder shall enter into a Contract with the City and furnish the required Performance and Payment Bonds and Certificates of Insurance or forfeit the Bid Bond or security as liquidated damages. A contract must be executed within ten (10) days following the award of the successful bidder Questions regarding this Request for Proposals shall be submitted to Laura Hammer, Grant Administrator, City of Fellsmere, 22 S. Orange Street, Fellsmere, FL 32948 or by email to grantadmin@cityoffellsmere.org. Questions must be received in writing no later than August 20, 2024. Answers to all questions received will be posted at online by no later than August 27, 2024. All responses shall be submitted in compliance with the requirements of the Request for Proposals. The City of Fellsmere is an Equal Opportunity Employer. WBE/MBE firms are encouraged to respond to this Request for Proposals. The City reserves the right to delay reviewing the responses for up to sixty (60) days after the response opening, to waive information in any response, or to reject any or all responses in whole or in part with or without cause that, in its judgment, will serve the best interests of the City. The method of Contractor Selection has not been Determined at this time